Loading...
Approve Bid for Lake Lucy Tower Recoating0 CITE OF CHANHASSEN 7700 Market Boulevard PO Box 147 Chanhassen, MN 55317 Administration Phone: 952.227.1100 Fax: 952.227.1110 Building Inspections Phone: 952.227.1180 Fax: 952.227.1190 Engineering Phone: 952.227.1160 Fax: 952.227.1170 Finance Phone: 952.227.1140 Fax: 952.227.1110 Park & Recreation Phone: 952.227.1120 Fax: 952.227.1110 Recreation Center 2310 Coulter Boulevard Phone: 952.227.1400 Fax: 952.227.1404 Planning & Natural Resources Phone: 952.227.1130 Fax: 952.2271110 Public Works 7901 Park Place Phone: 952.227.1300 Fax: 952.227.1310 Senior Center Phone: 952.227.1125 Fax: 952.227.1110 Website www.ci.chanhassen.mn.us MEMORANDUM TO: Todd Gerhardt, City Manager FROM: Paul Oehme, Director of Public Works /City Engineer DATE: December 14, 2015 O�� SUBJ: Approve Bid for Recoating Lake Lucy Ground Storage Reservoir to Classic Protective Coatings, Inc. Project No. PW158C2 PROPOSED MOTION "The City Council accepts the bids for recoating the Lake Lucy Ground Storage Reservoir, Project No. PW158C2 and awards a contract to Classic Protective Coatings, Inc. in the amount of $684,985 for Alternate A." City Council approval requires a simple majority vote of the City Council present. BACKGROUND The 3.5 million gallon Lake Lucy ground storage reservoir is located at 6581 Peaceful Lane and was constructed in 1987. The reservoir interior and exterior coatings are original with only minor exterior coating work completed in 2001. The coatings are now 28 years old and have served the City well having exceeded their expected design life of 25 years. A ROV (remotely operated underwater vehicle) inspection was completed in 2010 which showed some coating failure. The interior and exterior of the tank was reinspected this fall and the coatings were found to be failing. The exterior of the tank is beginning to show signs of flash rust. A minor recoating of the tank is not cost effective. Also, it is recommended the interior of the tank coating be replaced at this time. DISCUSSION The proposed project is to completely remove the old coating and repaint the interior and exterior of the tank. The tank is in a residential area so the tank will have to be fully covered or contained while the old coating is being Chanhassen is a Community for Life - Providing forTodayand Planning for Tomorrow Todd Gerhardt Lake Lucy Tower: Approve Bid for Recoating December 14, 2015 Page 2 removed and the tank is being painted. Some small structural improvements are necessary at this time along with minor electrical improvements. Two cellular providers are located on the tank so the equipment will have to be temporarily relocated for the duration of the project. BIDS The bid opening for the above referenced project was held on December 3, 2015 at 2:00 p.m. The following five (5) bids were received as follows: BIDDER Champion Coatings Inc. Classic Protective Coatings, Inc. George Kountoupes Painting Odland Protective Coatings TMI Coatings, Inc. Total Bid Amount Alternate "A" Alternate `B" $ 788,000 $ 788,000 $ 684,985 $ 684,958 Did Not Bid $ 837,000 $ 1,066,830 $ 1,066,830 $ 926,800 $ 926,800 The Engineer's cost estimate for this project was $907,500.00 for both Alternates. Alternate A has a spring construction start and Alternate B has a late summer construction start. Bids were tabulated and checked for errors. Classic Protective Coatings, Inc. was the low bidder. The company is located in Menomonie, Wisconsin. Reference checks have been made. Classic Protective Coatings Inc. have repainted water tanks in Maple Grove, Cottage Grove, Rogers, Shorewood and Bloomington in the past two years. They are one of the largest tank painters in the upper Midwest. The City's project consultant, Kollmer Consutants, Inc. (KCI), has reviewed the qualifications supplied by Classic Protective Coatings, Inc. and finds they meet the requirements of the Project Specifications. KCI recommends that Classic Protective Coatings, Inc., be awarded the contract for the Cleaning, Repairing and Painting of the 3.5 MMG Steel Ground Storage Reservoir. Staff recommends awarding a contract for Alternative A with a spring construction start. Two Chanhassen maple leaf logos will be repainted on the tank. Attachment: Resolution Letter from Kollmer Consultants, Inc. Classic Protective Coatings, Inc. Brochure Pages CIP Sheet gAeng \public \pw158c2 lake lucy reservior recoating \121415 bkgd award bid recoating tank.doc CITY OF CHANHASSEN CARVER AND HENNEPIN COUNTIES, MINNESOTA DATE: December 14, 2015 RESOLUTION NO: MOTION BY: SECONDED BY: 2015 -XX A RESOLUTION ACCEPTING BIDS AND AWARDING CONTRACT FOR RECOATING THE LAKE LUCY GROUND STORAGE RESERVOIR PW158C2 WHEREAS, pursuant to a request for bids for recoating the Lake Lucy Ground Storage Reservoir project, five bids were received and opened. The bids are as follows: BIDDER Champion Coatings Inc. Classic Protective Coatings, Inc. George Kountots Painting Odland Protective Coatings T1VII Coatings, Inc. Total Bid Amount Alternate "A Alternate "B" $ 788,000 $ 788,000 $ 684,985 $ 684,958 Did Not Bid $ 837,000 $ 1,066,830 $ 1,066,830 $ 926,800 $ 926,800 AND WHEREAS, Classic Protective Coatings, Inc. is the lowest responsible bidder with a total bid amount of $684,985.00 for Alternate A. NOW THEREFORE, BE IT RESOLVED by the Chanhassen City Council: The mayor and clerk are hereby authorized and directed to enter into a contract with Classic Protective Coatings, Inc. in the name of the City of Chanhassen for the Bluff Creek Drive /Mayapple Pass Intersection Improvement Project according to the plans and specifications therefore approved by the City Council and on file in the office of the city clerk. Passed and adopted by the Chanhassen City Council this 10 day of December, 2015. ATTEST: Todd Gerhardt, City Manager Denny Laufenburger, Mayor YES NO ABSENT KCI KoiMeer Consultanft, Irec., 7494 2531d Avenue NE, Stacy, MN 55079 Phone: (651) 462 -7266 Fax: (651) 462 -3249 December 7, 2015 Mr. Paul Oehme, PE Director of Public Works /City Engineer 7700 Market Blvd. PO Box 147 Chanhassen, MN 55317 Engineering, Coatings & Inspection Services Re: Tank Reconditioning Project 3.5 MMG Steel Ground Storage Reservoir Lake Lucy Road Reservoir City Project No. PW158C2 Bid Evaluation Dear Mr. Oehme: BY: Email The bid opening for the above referenced project was held on December 3, 2015 at 2:00 p.m. The following Five (5) bids were received as follows: BIDDER Total Bid Amount Alternate "A" Alternate "B" Champion Coatings Inc. $ 788,000 $788,000 Classic Protective Coatings, Inc. 684,985 684,958 George Kountoupes Painting Did Not Bid 837,000 Odland Protective Coatings 1,066,830 1,066,830 TMI Coatings, Inc. 926,800 926,800 The Engineer's cost estimate for this project was $907,500.00. .KCI recommends that Classic Protective Coatings, Inc., be awarded the contract for the Cleaning, Repairing and Painting of the 3.5 MMG Steel Ground Storage Reservoir, Lake Lucy Road Reservoir, City Project No. PW158C2, for either Alternate "A" for the Bid of $684,958.00 or Alternate "B" for the Bid of $684,958.00. 1 called Classic Protective Coatings, Inc. today Friday Dec. 4, 2015 and asked them if their Bid was correct and they said Yes. We have reviewed the qualifications supplied by Classic Protective Coatings, Inc.; KCI finds they meet the requirements of the Project Specifications. It is our understanding the Notice of Award and the Contract Documents will be sent to the Contractor you select by the City. If you have any questions regarding KCI's recommendation please call me at 651/462 -7266. Sincerely, KOLLMER CONSULTANTS, INC. Robert E. Kollmer, President Certified NACE International Coatings Inspector No. 1291 Maintaining Pride in the Community Classic Protective Coatings provides professional services for elevated water tanks, ground water tanks, and fuel storage tanks. Our skilled mechanics repair and maintain tanks, keeping them safe and up to code. We paint interior and exterior surfaces and do washout and dive tank inspections.We are fully qualified to modify tanks to meet OSHA and current security standards.We have built a sterling reputation with our clients for working quickly, safely, and with the community in mind. Maintenance and Negotiated Plans Maintaining quality water storage can be daunting. Our multi -year professional service agreements are designed to make that responsibility our concern.We work with you to assess your needs and agree upon a plan that meets your requirements.We work closely with top engineers to write the specifications and let you spread the cost over many years.You have the security of knowing that a company you can trust is ensuring the long life of your tank. Our containment systems completely cover the tank during blasting processes, protecting the community from contaminates and debris. State -of -the -art Equipment and Top -notch Crews Make Us Stand Out in a Crowd Equipment. Our welding, blasting, painting, and containment equipment is state -of- the -art. Protecting the community is our number one priority and our specialized containment systems are one of our most prized assets. Containment allows us to strip even contaminated surfaces dust -free. Our containment systems combined with our 40,000 CFM dust collector and our Monster Blaster, the largest mobile blaster in the industry, make an unbeatable team.The Monster Blaster's multiple hoses guarantee smooth work processes with minimal downtime. People. We work on tanks but we care about people. Our six - person crews have up -to- the - minute training on safety and compliance issues. Our company's culture encourages senior employees to mentor newer employees so the whole team works up to the highest standards. Our employees are passionate about the quality of their work and it shows. Our Versa -blast system has built in dust collection capabilities so no emissions are released into the air. It allows us to prepare flat surfaces quickly and safely without external containment. ho Partial list of clients: • Marietta, GA • Little Falls, MN • Loogootee, IN • Lake City, FL • North Richland Hills,TX • Leitchfield, KY • N.A.S.A. • Gainesville, GA • US Air Force • US Navy Classic Protective Coatings is affiliated with: AW WA American Water Works Association SSPC The Society for Protective Coatings Living Up to Our Reputation At Classic Protective Coatings, each job is unique. Our case file of hundreds of tanks means we have found solutions to that many different challenges. We have an excellent track record for working on tanks in tight spots with minimal disruption to the community. This tank in Cottage Grove, Minnesota, is surrounded by many homes. With 2.5 million gallons of water, the tank in Wauwatosa, Wisconsin, is one of the largest legged elevation water tanks in the country.We contained the tank and finished the project safely and ahead of schedule. Projects By Funding Source City of Chanhassen, MN Project # W -041 Project dame Repaint Lake Lucy Water Stand Pipe 2015 thru 2019 Department Water System Improvements Contact Paul Oehme Type Improvement Useful Life 1,100,000 2016 2017 Category Utilities Account #1 700 - 7025 -4751 Account #3 Priority n/a Account #2 Account #4 Description Total Project Cost: $1,100,000 This project will remove the existing exterior paint and repaint the interior and exterior surfaces of the Lake Lucy stand pipe. The exterior paint samples of the tank show the prime boat is too weathered to repaint and the existing paint has heavy metals and needs to be removed. Also, a structural analysis of the tank has shown supports in the interior of the tank need to be replaced. The tank was constructed in 1987 with an exterior coating placed in 2001. The base coat is now 27 years old and has served the City well, having exceeded the service life of 20 years. Justification kn inspection report will be dratted, prior to construction justifying the work. The tank was last painted in 2001. Expenditures 2015 2016 2017 2018 2019 Total Construction 1,100,000 1,100,000 Total Funding Sources 2015 1,100,000 2016 2017 1,100,000 2018 2019 Total Water Utility Fund 1,100,000 1,100,000 Total 1,100,000 1,100,000 Budget Impact/Other i i 1 , ►/ 17�I1I,7 ��1 ►% I �I�Y y BETWEEN CITY OF CHANHASSEN AND CONTRACTOR FOR LAKE LUCY 3.5 MMG GROUND STORAGE RESERVOIR RECOATING THIS AGREEMENT, made this 14th day of December, 2015, by and between the CITY OF CHANHASSEN, a Minnesota municipal corporation ( "Owner ") and CLASSIC PROTECTIVE COATINGS, INC. ( "Contractor "). Owner and Contractor, in consideration of the mutual covenants set forth herein, agree as follows: 1. CONTRACT DOCUMENTS. The following documents shall be referred to as the "Contract Documents ", all of which shall be taken together as a whole as the contract between the parties as if they were set verbatim and in full herein: A. This Agreement; B. Specifications dated November 20, 2015; C. City of Chanhassen General Conditions of the Construction Contract; D. Quote/Bid dated December 3, 2015. In the event of a conflict among the provisions of the Contract Documents, the order in which they are listed above shall control in resolving any such conflicts with Contract Document "A" having the first priority and Contract Document "D" having the last priority. 2. OBLIGATIONS OF THE CONTRACTOR. The contractor shall provide the goods, services, and perform the work in accordance with the Contract Documents. 3. CONTRACT PRICE. Owner shall pay Contractor for completion of the Work in accordance with the Contract Documents the amount of Six Hundred Eighty Four Thousand Nine Hundred Eighty Five & 00 /100 ($684,985.00). 4. PAYMENT PROCEDURES. A. Contractor shall submit Applications for Payment. Applications for Payment will be processed by Engineer as provided in the General Conditions. B. Progress Payments; Retainage. Owner shall make 95% progress payments on account of the Contract Price on the basis of Contractor's Applications for Payment during performance of the Work. C. Payments to Subcontractor. (1) Prompt Payment to Subcontractors. Pursuant to Minn. Stat. § 471.25, Subd. 4a, the Contractor must pay any subcontractor within ten (10) days of the Contractor's receipt of payment from the City for undisputed services provided by the subcontractor. The Contractor must pay interest of 1 %Z percent per month or any part of a month to the Subcontractor on any undisputed amount not paid on time to the subcontractor. The minimum monthly interest penalty payment for an unpaid balance of $100.00 or more is $10.00. For an unpaid balance of less than $100.00, the Contractor shall pay the actual penalty due to the subcontractor. (2) Form IC -134 (attached) required from general contractor. Minn. Stat. § 290.92 requires that the City of Chanhassen obtain a Withholding Affidavit for Contractors, Form IC -134, before making final payments to Contractors. This form needs to be submitted by the Contractor to the Minnesota Department of Revenue for approval. The form is used to receive certification from the state that the vendor has complied with the requirement to withhold and remit state withholding taxes for employee salaries paid. D. Final Payment. Upon final completion of the Work, Owner shall pay the remainder of the Contract Price as recommended by Engineer. 5. COMPLETION DATE/LIQUIDATED DAMAGES. A. The Work must be completed and storage reservoir must be put back into service on or before July 29, 2016 in accordance with the Special Provisions and General Conditions. B. Contract and Owner recognize that time is of the essence of this Agreement and that Owner will suffer financial loss if the Work is not completed within the times specified in Paragraph 5.A. above, plus any extensions thereof allowed. The parties also recognize the delays, expense, and difficulties involved in proving in a legal or arbitration proceeding the actual loss suffered by Owner if the Work is not completed on time. Accordingly, instead of requiring any such proof, Owner and Contractor agree that as liquidated damages for delay (but not as a penalty), Contractor shall pay Owner $ 750.00 for each calendar day that expires after the time specified in Paragraph 5.A. for Completion until the Work is complete. Daily costs are based on MnDOT Table 1807 -1, "Schedule of Liquidated Damages as follows: 2 TABLE 1807 -1 SCHEDULE OF LIQUIDATED DAMAGES Original Contract Amount Charge Per Cal. Day ($) From More Than ($) To and Including ($ 0 25,000 75 25,000 50,000 125 50,000 100,000 250 100,000 500,000 500 500,000 1,000,000 750 1,000,000 2,000,000 1,250 2,000,000 5,000,000 1,750 5,000,000 10,000,000 2,500 10,000,000 - - -- 3,000 6. CONTRACTOR'S REPRESENTATIONS. A. Contractor has examined and carefully studied the Contract Documents and other related data identified in the Contract Documents. B. Contractor has visited the Site and become familiar with and is satisfied as to the general, local, and Site conditions that may affect cost, progress, and performance of the Work. C. Contractor is familiar with and is satisfied as to all federal, state, and local Laws and Regulations that may affect cost, progress, and performance of the Work. D. Contractor has carefully studied all: (1) reports of explorations and tests of subsurface conditions at or contiguous to the Site and all drawings of physical conditions in or relating to existing surface or subsurface structures at or contiguous to the Site (except Underground Facilities) which have been identified in the General Conditions and (2) reports and drawings of a Hazardous Environmental Condition, if any, at the site. E. Contractor has obtained and carefully studied (or assumes responsibility for doing so) all additional or supplementary examinations, investigations, explorations, tests, studies, and data concerning conditions (surface, subsurface, and Underground Facilities) at or contiguous to the Site which may affect cost, progress, or performance of the Work or which relate to any aspect of the means, methods, techniques, sequences, and procedures of construction to be employed by Contractor, including any specific means, methods, techniques, sequences, and procedures of construction expressly required by the Bidding Documents, and safety precautions and programs incident thereto. F. Contractor does not consider that any further examinations, investigations, explorations, tests, studies, or data are necessary for the performance of the Work at the Contract Price, within the Contract Times, and in accordance with the other terms and conditions of the Contract Documents. G. Contractor is aware of the general nature of work to be performed by Owner and others at the Site that relates to the Work as indicated in the Contract Documents. H. Contractor has correlated the information known to Contractor, information and observations obtained from visits to the Site, reports and drawings identified in the Contract Documents, and all additional examinations, investigations, explorations, tests, studies, and data with the Contract Documents. I. Contractor has given Engineer written notice of all conflicts, errors, ambiguities, or discrepancies that Contractor has discovered in the Contract Documents, and the written resolution thereof by Engineer is acceptable to Contractor. The Contract Documents are generally sufficient to indicate and convey understanding of all terms and conditions for performance and furnishing of the Work. K. Subcontracts: (1) Unless otherwise specified in the Contract Documents, the Contractor shall, upon receipt of the executed Contract Documents, submit in writing to the Owner the names of the Subcontractors proposed for the work. Subcontractors may not be changed except at the request or with the consent of the Owner. (2) The Contractor is responsible to the Owner for the acts and omissions of the Contractor's subcontractors, and of their direct and indirect employees, to the same extent as the Contractor is responsible for the acts and omissions of the Contractor's employees. (3) The Contract Documents shall not be construed as creating any contractual relation between the Owner, the Engineer, and any Subcontractor. 4 (4) The Contractor shall bind every Subcontractor by the terms of the Contract Documents. 7. WORKER'S COMPENSATION. The Contractor shall obtain and maintain for the duration of this Contract, statutory Worker's Compensation Insurance and Employer's Liability Insurance as required under the laws of the State of Minnesota. 8. COMPREHENSIVE GENERAL LIABILITY. Contractor shall obtain the following minimum insurance coverage and maintain it at all times throughout the life of the Contract, with the City included as an additional name insured on a primary and non- contributory basis. The Contractor shall furnish the City a certificate of insurance satisfactory to the City evidencing the required coverage: Bodily Injury: Property Damage: $2,000,000 each occurrence $2,000,000 aggregate products and completed operations $2,000,000 each occurrence $2,000,000 aggregate Contractual Liability (identifying the contract): Bodily Injury: $2,000,000 each occurrence Property Damage: $2,000,000 each occurrence $2,000,000 aggregate Personal Injury, with Employment Exclusion deleted: $2,000,000 aggregate Comprehensive Automobile Liability (owned, non - owned, hired): Bodily Injury: $2,000,000 each occurrence $2,000,000 each accident Property Damage: $2,000,000 each occurrence 9. WARRANTY. The Contractor guarantees that all new equipment warranties as specified within the quote shall be in full force and transferred to the City upon payment by the City. The Contractor shall be held responsible for any and all defects in workmanship, materials, and equipment which may develop in any part of the contracted service, and upon proper notification by the City shall immediately replace, without cost to the City, any such faulty part or parts and damage done by reason of the same in accordance with the bid specifications. 10. INDEMNITY. The Contractor agrees to indemnify and hold the City harmless from any claim made by third parties as a result of the services performed by it. In addition, the Contractor shall reimburse the City for any cost of reasonable attorney's fees it may incur as a result of any such claims. 11. MISCELLANEOUS. A. Terms used in this Agreement have the meanings stated in the General Conditions. B. Owner and Contractor each binds itself, its partners, successors, assigns and legal representatives to the other party hereto, its partners, successors, assigns and legal representatives in respect to all covenants, agreements, and obligations contained in the Contract Documents. C. Any provision or part of the Contract Documents held to be void or unenforceable under any Law or Regulation shall be deemed stricken, and all remaining provisions shall continue to be valid and binding upon Owner and Contractor, who agree that the Contract Documents shall be reformed to replace such stricken provision or part thereof with a valid and enforceable provision that comes as close as possible to expressing the intention of the stricken provisions. D. Data Practices/Records. (1) All data created, collected, received, maintained or disseminated for any purpose in the course of this Contract is governed by the Minnesota Government Data Practices Act, Minn. Stat. Ch. 13, any other applicable state statute, or any state rules adopted to implement the act, as well as federal regulations on data privacy. (2) All books, records, documents and accounting procedures and practices to the Contractor and its subcontractors, if any, relative to this Contract are subject to examination by the City. E. Software License. If the equipment provided by the Contractor pursuant to this Contract contains software, including that which the manufacturer may have embedded into the hardware as an integral part of the equipment, the Contractor shall pay all software licensing fees. The Contractor shall also pay for all software updating fees for a period of one year following cutover. The Contractor shall have no obligation to pay for such fees thereafter. Nothing in the software license or licensing agreement shall obligate the City to pay any additional fees as a condition for continuing to use the software. F. Patented devices, materials and processes. If the Contract requires, or the Contractor desires, the use of any design, devise, material or process covered by letters, patent or copyright, trademark or trade name, the I Contractor shall provide for such use by suitable legal agreement with the patentee or owner and a copy of said agreement shall be filed with the Owner. If no such agreement is made or filed as noted, the Contractor shall indemnify and hold harmless the Owner from any and all claims for infringement by reason of the use of any such patented designed, device, material or process, or any trademark or trade name or copyright in connection with the Project agreed to be performed under the Contract, and shall indemnify and defend the Owner for any costs, liability, expenses and attorney's fees that result from any such infringement G. Assignment. Neither party may assign, sublet, or transfer any interest or obligation in this Contract without the prior written consent of the other party, and then only upon such terms and conditions as both parties may agree to and set forth in writing. H. Waiver. In the particular event that either party shall at any time or times waive any breach of this Contract by the other, such waiver shall not constitute a waiver of any other or any succeeding breach of this Contract by either party, whether of the same or any other covenant, condition or obligation. I. Governing LawNenue. The laws of the State of Minnesota govern the interpretation of this Contract. In the event of litigation, the exclusive venue shall be in the District Court of the State of Minnesota for Carver County. J. Severability. If any provision, term or condition of this Contract is found to be or become unenforceable or invalid, it shall not affect the remaining provisions, terms and conditions of this Contract, unless such invalid or unenforceable provision, term or condition renders this Contract impossible to perform. Such remaining terms and conditions of the Contract shall continue in full force and effect and shall continue to operate as the parties' entire contract. K. Entire Agreement. This Contract represents the entire agreement of the parties and is a final, complete and all inclusive statement of the terms thereof, and supersedes and terminates any prior agreement(s), understandings or written or verbal representations made between the parties with respect thereto. L. Permits and Licenses; Rights -of -Way and Easements. The Contractor shall procure all permits and licenses, pay all charges and fees therefore, and give all notices necessary and incidental to the construction and completion of the Project. The City will obtain all necessary rights -of- way and easements. The Contractor shall not be entitled to any additional 7 compensation for any construction delay resulting from the City's not timely obtaining rights -of -way or easements. M. If the work is delayed or the sequencing of work is altered because of the action or inaction of the Owner, the Contractor shall be allowed a time extension to complete the work but shall not be entitled to any other compensation. CITY OF CHANHASS N BY: 40-� 4��= Denny L ufennbbu(ger, Mayor BY: ✓�'4"r l 1 Add Gerhardt, City Manager CLASSIC PROTECTIVE COATINGS, INC. C 5dt. •'1+ Its Sedefoxv Payment bond Page 2 Bond # 929627710 ' PAYMENT BOND KNOW ALL MEN BY THESE PRESENTS: that Classic Protective Coatings, Inc. (Here insert the name and address of the legal title of the Contractor) as Principal, hereinafter called the Contractor and _Western Surety Company (Here insert the legal title of the Surety) as Surety, hereinafter called the Surety, are held and firmly bound unto the City of Chanhassen, Minnesota as obligee, hereinafter called the Owner, in the amount of Six Hundred Eighty Four Thousand Nine Hundred Eighty Five and 00/100 -- Dollars ($684,985.00 ----- 7 for payment whereof Contractor and Surety bind themselves, their heirs, executors, administrators, successors, and assigns jointly and severally, firmly by these presents. WHEREAS, Contractor has by written agreement dated December 14, 2015 2015, entered into a Contract with Owner for: CLEANING, REPAIRING AND PAINTING OF A 3.5 MMG STEEL GROUND STORAGE RESERVOIR LAKE LUCY ROAD RESERVOIR CITY PROJECT NO, PW958C2 in accordance with plans and specifications prepared by Kollmer Consultants, Inc., Inc., which contract is by reference made apart hereof, and is hereinafter referred to as the Contract. NOW, THEREFORE, THE CONDITION OF THIS OBLIGATION is such that, if Contract shall promptly and faithfully perform said Contract, then the obligation of this bond shall be null and void; otherwise it shall remain in full force and effect. A. The Surety hereby waives notice of any alteration or extension of time made by the Owner. B. Whenever Contractor shall be and is declared by Owner to be, in default under the Contract, the Owner having performed Owner's obligations thereunder, the Surety may promptly remedy the default, or shall promptly: 1. Complete the Contract in accordance with its terms and conditions, or Obtain a bid or bids for submission to Owner for completing the Contract in accordance with its terms and conditions, and upon determination by Owner and Surety of the lowest responsible bidder, arrange a contract between such bidder and Owner, and make available as work progresses (even though there should be a default or a succession of defaults under the Contract or contracts of completion arranged under this paragraph) sufficient funds to pay the cost of completion less the balance of the Contract Price; but not exceeding including other costs and damages for which the Surety may be liable hereunder, the amount set forth in the first paragraph hereof. The term "balance of the Contract Price," as used in this paragraph, shall mean the total amount payable by Owner to Contractor under the Contact and any amendments thereto less the amount properly paid by Owner to Contractor. Payment'Bond Page 3 C. No right of action shall accrue to or for the use of any person or corporation other than i the Owner named herein or the heirs, executor, administrators, or successors of Owner. IT IS A FURTHER CONDITION OF THIS OBLIGATION that the Contractor and Surety shall pay to all persons, firms, or corporation having contracts directly with the Contractor or with subcontractors all just claims due them for labor performed or materials furnished in the performance of the contract on account of which this bond is given. t SIGNED AND SEALED THIS 8th day of January 1 A.D., 20 16 IN THE PRESENCE OF: Classic Protective Coatings, Inc. ► 11lJL W By WITNESS U PRINCIPA I President TITLE I Ray Witke I CONTRACTOR'S NAME I N 7670 State Hwy 25, Menomonie, WI 54751 CONTRACTOR'S ADDRESS Western Sur any By ► T ESS SURET Attorney -in -Fact TITLE Stephen M Klein SURETY'S NAME 333 S Wabash Ave.,41 Fl, Chicago, IL 60604 SURETY'S ADDRESS KLEIN AGENCY, INC, 3570 No. Lexington Ave, Ste. 206 St, Paul, MN 55126 (651) 484 -6461 Note: Please attach a certified and current copy of a Power of Attorney. M Performance Bond Page 2 PERFORMANCE BOND i KNOW ALL PERSONS: That we, Classic Protective Coatings, Inc. i of Menomonie, WI hereinafter called the "Principal ", and Western Surety Company hereinafter called the "Surety ", are held firmly bound x Hundred Eighty Four Thousand Nine i unto the City of Chanhassen, Minnesota, hereinafter called the Owner, in the sum of $ Hundred Eighty Five and 00/100 Dollars ($ 684,985.00-------------- - - - - -- ), for the payment whereof the Principal and the Surety bind themselves, their heirs, executors, administrators, successors and assigns, jointly and severally, firmly, by these presents. WHEREAS, the Principal has, by means of a written Agreement dated December 14 , 2015, t entered into a Contract with the City of Chanhassen for: Cleaning, Repairing and Painting of a 3.5 MMG Steel Ground Storage Reservoir, which Agreement includes a guarantee of all work against defective workmanship and materials for a period of two years from the date of final acceptance of the work by the City of Chanhassen, a copy of which Agreement is by reference made a part hereof; Now Therefore, the condition of this Obligation is such that, if the Principal shall faithfully perform the Contract on his part and shall fully indemnify and save harmless the City of i Chanhassen from all cost and damage which he may suffer by reason of failure so to do and shall fully reimburse and repay the City of Chanhassen all outlay and expense which the Water Works may incur in making good any such default, And Further, that if the Principal shall pay all persons who have contracts directly with the Principal for labor or materials, failing which such persons shall have a direct right of action i against the Principal and Surety under this Obligation, subject to the City of Chanhassen priority, Then this Obligation shall be null and void, otherwise it shall remain in full force and effect. Provided, however, that no suit, action or proceeding by reason of any default whatever shall be brought on this Bond after two years from the date of final acceptance of the work. And Provided, that any alterations which may be made in the terms of the Contract, or in the work to be done under it, or the giving by the City of Chanhassen of any extension of time for the performance of the Contract, or any other forbearance on the part of either the City of Chanhassen or the Principal to the other shall not in any way release the Principal and the Surety, or either of them, their heirs, executors, administrators, successors or assigns from their liability hereunder, notice to the Surety of any such alteration, extension or forbearance being hereby waived. Performance Bond Page 3 And Further Provided, the Principal and Surety on the Bond hereby agree to pay all persons, firms, or corporations having contracts directly with the Principal or with subcontractors all just claims due them for labor performed or material furnished, in the performance of the Contract on account of which this Bond is given, when the same are not satisfied out of the portion of the contract price which the City of Chanhassen shall retain until completion of the improvements, but the Principal and Surety shall not be liable to said person, firms, or corporations unless the claims of said claimants against said portions of the contract price shall have been established as provided by Law. The Surety on this Bond shall be deemed and held, any contract to the contrary not withstanding, to consent without notice: a. To the extension of time to the Principal in which to perform the contract. b. To changes in the plans, specifications, or Contract, when such changes do not involve and increase of more than twenty percent (20 %) of the total price and shall then be released only as to such excess increases. C. That no provision of this Bond or of any other contract shall be valid which limits to less than two (2) years from the date of final acceptance of the work the right to sue on this Bond for defects in workmanship or materials not discovered or know to the City of Chanhassen at the time such work was accepted. The Bond is executed in duplicate. Signed and sealed this 8th day of January , A.D., 2016 IN THE PRESENCE OF: Classic Protective Coatings, Inc. L W lJx By _ WITNESS PRINCIPA President TITLE Ray Witke CONTRACTOR'S NAME N 7670 State Hwy 25, Menomonie, WI 54751 CONTRACTOR'S ADDRESS Western " pany By WIN SUR Y Attorney -in -Fact TITLE Stephen M Klein SURETY'S NAME 333 S Wabash Ave.,41 Fl, Chicago, IL 60604 SURETY'S ADDRESS KLEIN AGENCY, INC. Note: Please attach a certified and current copy of a Power of Attorney570 No. Lexington Ave. Ste. 206 St. Paul, MN 55126 (651) 484 -6461 INDIVIDUAL OR PARTNERSHIP ACKNOWLEDGMENT STATE OF COUNTY OF On this personally appeared to me known to be the person bond, and acknowledged that act and deed. day of he , before me described in and who executed the forgoing executed the same as free Notary Public CORPORATION ACKNOWLEDGMENT STATE OF uvi2)Cn2)Ln COUNTY OF T:)LLn n On this I day of a Lo , before me personally came to me known, who being by me duly sworn, did depo e and say; that he is the of Classic Protective Coatings, Inc. , the corporation described in and which executed the above instrument; that he knows the seal of said corporation; affixed by order of the Board of Directors of said corporation, and that he signed his name thereto by like order. treerorr� 011) er yy. MQ, ........ ,t �, a : Notd/ •. i SURETY ACKNOWLEDGMENT s %% UWIG ••r •••ANN••••• STATE OF MINNESOTA �i� Of WI �� %%%%� COUNTY OF RAMSEY On this 8th day of January , 2016 , before me appeared Stephen M. Klein to me personally known, who, being duly sworn, did say that he is the Attorney -In -Fact of Western Surety Company of Sioux Falls, South Dakota that the seal affixed to the foregoing instrument is the corporation seal of said corporation; that the said instrument was signed and sealed on behalf of said corporation by authority of its Board of Directors; and he did also acknowledge that he executed the said instrument as the free act and deed of said Company. W, o Public E.. " . KARLA DEUTSCH HUNT NOTARY PUBLIC - MINNESOTA e 2017 k My Commission Expires Jan. 31, Western Surety Company POWER OF ATTORNEY APPOINTING INDIVIDUAL ATTORNEY -IN -FACT Know All Men By These Presents, That WESTERN SURETY COMPANY, a South Dakota corporation, is a duly organized and existing corporation having its principal office in the City of Sioux Falls, and State of South Dakota, and that it does by virtue of the signature and seal herein affixed hereby make, constitute and appoint John David Klein, John C Klein, Stephen M Klein, Kristin M Bakos, Individually of Saint Paul, MN, its true and lawful Attomey(s) -in -Fact with full power and authority hereby conferred to sign, seal and execute for and on its behalf bonds, undertakings and other obligatory instruments of similar nature - In Unlimited Amounts - and to bind it thereby as fully and to the same extent as if such instruments were signed by a duly authorized officer of the corporation and all the acts of said Attorney, pursuant to the authority hereby given, are hereby ratified and confirmed. This Power of Attorney is made and executed pursuant to and by authority of the By -Law printed on the reverse hereof, duly adopted, as indicated, by the shareholders of the corporation. In Witness Whereof, WESTERN SURETY COMPANY has caused these presents to be signed by its Vice President and its corporate seal to be hereto affixed on this 16th day of November, 2015. WESTERN SURETY COMPANY o ow/ 00904.4 " ;y s�►i/ oii aul T. Bruflat, Vice President State of South Dakota 1 J? ss County of Minnehaha On this 16th day of November, 2015, before me personally came Paul T. Bruflat, to me known, who, being by me duly sworn, did depose and say: that he resides in the City of Sioux Falls, State of South Dakota; that he is the Vice President of WESTERN SURETY COMPANY described in and which executed the above instrument; that he knows the seal of said corporation; that the seal affixed to the said instrument is such corporate seal; that it was so affixed pursuant to authority given by the Board of Directors of said corporation and that he signed his name thereto pursuant to like authority, and acknowledges same to be the act and deed of said corporation. My commission expires •4.ti4.w.+`+'w "w+,+.w4. +'ww• i S. EICH ; February 12, 2021( NOTARY KGTl1 r 9411TH OA �444444+�4444444414444444 �' S. Eich, Notary Public CERTIFICATE I, L. Nelson, Assistant Secretary of WESTERN SURETY COMPANY do hereby certify that the Power of Attorney hereinabove set forth is still in force, and further certify that the By -Law of the corporation printed on the reverse hereof is still in force. In testimony whereof I have hereunto subscribed my name and affixed the seal of the said corporation this 8th day of January, 2016 ,I*R T�0) �• WESTERN SURETY COMPANY �,P0AS � / v L. Nelson, Assistant Secretary Form F4280 -7 -2012 Authorizing By -Law ADOPTED BY THE SHAREHOLDERS OF WESTERN SURETY COMPANY This Power of Attorney is made and executed pursuant to and by authority of the following By -Law duly adopted by the shareholders of the Company. Section 7. All bonds, policies, undertakings, Powers of Attorney, or other obligations of the corporation shall be executed in the corporate name of the Company by the President, Secretary, and Assistant Secretary, Treasurer, or any Vice President, or by such other officers as the Board of Directors may authorize. The President, any Vice President, Secretary, any Assistant Secretary, or the Treasurer may appoint Attorneys in Fact or agents who shall have authority to issue bonds, policies, or undertakings in the name of the Company. The corporate seal is not necessary for the validity of any bonds, policies, undertakings, Powers of Attorney or other obligations of the corporation. The signature of any such officer and the corporate seal may be printed by facsimile. ACOWif ..�„ CERTIFICATE OF LIABILITY INSURANCE DATE (MM /DD /YYYY) 1/8/2016 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER, AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder is an ADDITIONAL INSURED, the policy(ies) must be endorsed. If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). PRODUCER KLEIN AGENCY INC 3570 N Lexington Ave #206 NAME: TSteve Klein PHONE FAX 651 4 ( EXt: (651) 484 -6461 A/C No:( ) 84 -6861 ANo ADDRESS:steveklein @kleinagency. com St Paul, MN 55126 -2805 INSURER(S) AFFORDING COVERAGE NAICp INSURERA:Illinois Union Ins. 27960 INSURED INSURER B: Navigators Specialty Ins. Co. 36056 $ 1,000 000 INSURER C : Great American Ins. CO. 16691 INSURER D: Classic Protective Coatings, Inc. INSURER E N 7670 State Hwy 25 INSURER F: $ lOO OOO Menomonie, WI 54751 COVERAGES CERTIFICATE NUMBER: REVISION NUMBER: THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. INSIR LTR TYPE OF INSURANCE ADDL INSD SUBR WVD POLICY NUMBER POLICY EFF MMIDD/YYYY POLICY EXP MM /DD/YYYY LIMITS X COMMERCIAL GENERAL LIABILITY EACH OCCURRENCE $ 1,000 000 CLAIMS -MADE _ OCCUR 0" EN PREMISES Ea occurrence $ lOO OOO X MEDEXP(Anyoneperson) $ 5 000 CG00010413 624087402007 8/28/158/28/16 X Contractual PERSONAL &ADVINJURY $ 1,000,000 A x GEN'L AGGREGATE LIMIT APPLIES PER: GENERAL AGGREGATE $ 2 , 000 , 000 PRODUCTS - COMP /OP AGG $ 2 , OOO , OOO POLICY C JECOT CI LOC $ OTHER: AUTOMOBILE LIABILITY INGLE L Ea accident $ BODILY INJURY (Per person) $ ANYAUTO BODILY INJURY (Per accident) $ ALL OWNED SCHEDULED AUTOS AUTOS NON -OWNED P Oacc identDAMAGE $ HIRED AUTOS AUTOS X UMBRELLA LIAB X OCCUR CHI5EXC3947901C 8/28 /158 /28/16 EACH OCCURRENCE $10 , 000 , 000 B EXCESS LIAB CLAIMS -MADE x AGGREGATE $lO,000,OOO DED X RETENTION$ lO OOO $ WORKERS COMPENSATION H STATUTE ER AND EMPLOYERS' LIABILITY y/N ANY PROPRIETOR/PARTNER/EXECUTIVE E.L. EACH ACCIDENT $ OFFICERIMEMBER EXCLUDED? (Mandatory in NH) E.L. DISEASE - EA EMPLOYE $ E.L. DISEASE - POLICY LIMIT $ If yes, describe under DESCRIPTION OF OPERATIONS below $2,000,000 Limit C BUILDERS RISK IMP6077083 -09 12/15/15 12/15/16 PER LOCATION 5 000 DEDUCTIBLE DESCRIPTION OF OPERATIONS / LOCATIONS / VEHICLES (ACORD 101, Additional Remarks Schedule, may be attached if more space is required) Project: PW158C2, Lake Lucy 3.5 MMG Ground Storage Reservoir Recoating Project. City of Chanhassen is named as additional insured on a primary and non- contributory basis where required by written contract per the endorsement attached to the policy. CERTIFICATE HOLDER CANCELLATION City of Chanhassen SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE 7700 Market Blvd THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN ACCORDANCE WITH THE POLICY PROVISIONS. Chanhassen, MN 55317 AUTHORIZED REP A E I ©1988 -2014 ACORD CORPORATION. All rights reserved. ACORD25(2014/01) The ACORD name and logo are registered marks of ACORD A`� °® CERTIFICATE OF LIABILITY INSURANCE DATE 01 /08/2016 ) 01/08/2016 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER, AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder is an ADDITIONAL INSURED, the policy(ies) must be endorsed. If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). PRODUCER Willis of Wisconsin, Inc. CONTACT NAME: c/o 26 Century Blvd P.O. Box 305191 Nashville, TN 372305191 USA PHONE FAX C No Ext:1 -877- 945 -7378 (A/C. No:1- 888- 467 -2378 E -MAIL ADDRESS: certificates@willis.com INSURERS AFFORDING COVERAGE NAIC # INSURERA:Ar onaut Insurance Company 19801 INSUREDClassic Protective Coatings Inc. INSURER B: N7670 State Hwy 25 Menomonie, WI 547515928 INSURER C: PERSONAL & ADV INJURY $ INSURER D: GENERAL AGGREGATE INSURER E: PRODUCTS - COMP /OP AGG $ INSURER F: $ COVERAGES CERTIFICATE NUMBER:W1273102 REVISION NUMBER: THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. INSR LTR TYPE OF INSURANCE A L UBR POLICY NUMBER POLICY EFF MM /DD POLICY EXP MM /DD LIMITS COMMERCIAL GENERAL LIABILITY CLAIMS -MADE F7 OCCUR EACH OCCURRENCE $ DAMA T RENTED PREMISES Ea occurrence $ MED EXP (Anyone person) $ PERSONAL & ADV INJURY $ GEN'L AGGREGATE LIMIT APPLIES PER: POLICY PRO- JECT F_� LOC OTHER: GENERAL AGGREGATE $ PRODUCTS - COMP /OP AGG $ $ AUTOMOBILE LIABILITY ANY AUTO ALL OWNED SCHEDULED AUTOS AUTOS HIRED AUTOS NON -OWNED AUTOS COMBINED SINGLE LIMIT Ea accident $ BODILY INJURY (Per person) $ BODILY INJURY (Per accident) $ PROPERTY DAMAGE Per accident $ UMBRELLA LIAB EXCESS LIAB OCCUR CLAIMS -MADE EACH OCCURRENCE $ AGGREGATE $ DED RETENTION$ $ A WORKERS COMPENSATION AND EMPLOYERS' LIABILITY Y/ N ANY PROPRIETOR /PARTNER/EXECUTIVE OFFICER /MEMBER EXCLUDED? [ (Mandatory in NH) If yes, describe under DESCRIPTION OF OPERATIONS below N/A WC 928068262684 09/20/2015 09/20/2016 X PER OTH- STATUTE ER E.L. EACH ACCIDENT $ 1,000,000 E.L. DISEASE - EA EMPLOYE9 $ 1,000,000 E.L. DISEASE - POLICY LIMIT 1 $ 1,000,000 DESCRIPTION OF OPERATIONS / LOCATIONS / VEHICLES (ACORD 101, Additional Remarks Schedule, may be attached if more space is required) Re: Lake Lucy 3.5 MMG Ground Storage Reservoir Recoating Project. City of Chanhassen 7700 Market Boulevard fhanhassen, MN 55317 I;ANI;LLLA I IUN SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN ACCORDANCE WITH THE POLICY PROVISIONS. AUTHORIZED REPRESENTATIVE ©1988 -2014 ACORD CORPORATION. All rights reserved. ACORD 25 (2014/01) The ACORD name and logo are registered marks of ACORD SR ID :11043342 BATCH:Batch #: 195972 s �-- � I 0 UtKI11-K ATE OF LIABILITY INSURANCE DATE (MLI/DD/YYYY) THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE U7,08,2016 OLDER. THIS H CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDEd BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER, AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder Is an ADDITIONAL INSURED, the pollcy(les) must be endorsed. If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement A statement on this certificate does not confer rights to the certificate holder In lieu of such endorsement(s), PRODUCER ......�.,.� INSURED Corey - Burstad insurance Agency 420 E. Main Street Menomonie, WI 54751 Classic Protective Coatings Inc N7670 State Road 25 Menomonie, WI 54751 -5928 nnucoxr_ce Stefanie I (AIC: No. E_*n, 715 -235 -6479 I i-"A Not: 715- 235-8860 c: RCYIJIVIY IrUMCSCK: 1 THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. L TR TYPE OF INSURANCE AD 114 n SU8 POLICY NUMBER hPjM+ppIYEYYYY MN DOfYYWy LIMITS COMMERCIAL GENERAL LIABILITY CLAIMS -MADE 7 OCCUR EACH OCCURRENCE $ NTED PREMISE e ocw $ MED EXP (Any one person) $ PERSONAL & ADV INJURY $ GEITL AGGREGATE LIMIT APPLIES PER: POLICY F-1 JECOT LOC OTHER: GENERAL AGGREGATE S PRODUCTS - COMP /OP AGG $ E A AUTOMOBILE X LIABILITY ANY AUTO AALLO ED X SCHEDULED AUTOS HIRED AUTOS X AUTO-0 ED Y 4481550200 12112/2015 12/1212016 CEOMB�1N of*) SINGLE LIMIT $ BODILY INJURY (Per person) $ 1,000,000 BODILY INJURY (Per accident) $ 1 00000 PReOP;NagAMAGE a 1000 000 $ UMBRELLA LIAS EXCESS LIAR HCLAIMS-MAIDE OCCUR EACH OCCURRENCE $ AGGREGATE E DED RETENTION $ f WORKERS COMPENSATION AND EMPLOYERS' LIABILITY YIN ANY PROPRIETORIPARTNER/EXECUTIVE OFFICERIMEMBER EXCLUDED? (Mandatory in NH) tt yyeess desuibe under DESCRIPTION OF OPERATIONS below NIA PER OTH- STATUTE I i ER E. L. EACH ACCIDENT S E.L. DISEASE - EA EMPLOYE $ E.L. DISEASE- POLICY LIMIT $ DESCRIP71ON m OF OPERATIONS I LOCATIONS 1 VEHICLES (ACORD 101, Additional Remarks Schedule, may be attached I more apace Is required) Lake Lucy 3.5 MMG Ground Storage Reservoir Recoating Project Certificate holder is listed as additional insured. CERTIFICATE HOLDER CANCELLATION 1988 -2014 ACORD CORPORATION. All rights reserved. ACORD 25 (2014101) The ACORD name and logo are registemIvmarks of ACORD Printed by SNR on January 08, 2016 at 12:12PM SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE City of Chanhassen THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN ACCORDANCE WITH THE POLICY PROVISIONS. 7700 Market Boulevard Chanhassen, MN 55317 AUTH Ii REPRESENTA -LIVE SNR 1988 -2014 ACORD CORPORATION. All rights reserved. ACORD 25 (2014101) The ACORD name and logo are registemIvmarks of ACORD Printed by SNR on January 08, 2016 at 12:12PM