Loading...
2016 Sanitary Sewer Televising (I/I) Project No. 16-02: Approve Quote0 CITY OF CgANAASSEN 7700 Market Boulevard PO Box 147 Chanhassen, MN 55317 Administration Phone: 952.227.1100 Fax: 952.227.1110 Building Inspections Phone: 952.227.1180 Fax: 952.227.1190 Engineering Phone: 952.227.1160 Fax: 952.227.1170 Finance Phone: 952.227.1140 Fax: 952.227.1110 Park & Recreation Phone: 952.227.1120 Fax: 952.227.1110 Recreation Center 2310 Coulter Boulevard Phone: 952.227.1400 Fax: 952.227.1404 rs MEMORANDUM TO: Paul Oehme, Director of Public Works /City Engine, - FROM: Stephanie Smith, Project Engineer k_C-5�1 - DATE: June 13, 2016 SUBJ: 2016 Sanitary Sewer Televising (I /I) Project No. 16 -02: Approve Quote PROPOSED MOTION "The City Council approves a quote for the 2016 Sanitary Sewer Re- Televising (I /I) Project No. 16 -02 to Pipe Services Corporation in the amount of $39,640.11." City Council approval requires a simple majority vote of the City Council present. DISCUSSION The Metropolitan Council is currently monitoring the flow of sanitary sewer from each city to determine the amount of Inflow and Infiltration (I/I) to the Met Council's treatment plant. If the city exceeds the allowance set by the Met Council, the city will be surcharged a fee based on the amount of flow above the allowed amount. This project will help reduce 1/1 from entering the sanitary sewer system. The 2016 Sanitary Sewer Televising (I /I) project will assist city staff in locating inflows and other contributors to 1/1 in the city's sanitary sewer system. Sanitary sewer televising consists of cleaning out the sanitary sewer and recording video of the lengths of pipe in the project area. The contractor will report the deficiencies observed during the video examination of the pipes. Planning & On April 27, 2015, City Council approved initial televising for sanitary sewer areas Natural Resources Phone: 952.227.1130 for the 2016 I/I Project. Televising data collected at that time showed that the Fax: 952.227.1110 concrete pipe along Audubon Road was in better condition than anticipated. Staff does not recommend I/I maintenance in that area at this time. Public Works 7901 Park Place Staff recommends televising the area that is serviced by Lift Station No 2. This lift Phone: 952.227.1300 station shows an increase in pumping during rain events that signals an I/I problem. Fax: 952.227.1310 The information obtained from the 2016 Sanitary Sewer Re- televising (I /I) will be used to plan what sanitary sewer repairs will be included as part of the 2016 UI Senior Center Phone: 952.227.1125 Project. It also includes televising for the 2017 Street Improvement Projects in the Fax: 952.227.1110 Lake Susan and Saddlebrook neighborhoods. Website Bidder Base Bid www.ci.chanhassen.mn.us Pipe Services Corporation* $39,640.11 Hydro Klean $56,132.66 *Notes recommended items to be awarded. g: \eng \publltc_�e s'�1t5- c�jel< \Ctfmmibi{��tf� T8l1�YLYWrbVPffi4eTANY Lte.dc The City of Chanhassen put out a request for quotes from three contractors on May 6, 2016. Two quotes were received. The low quote for this project was from Pipe Services Corporation. This contractor has completed work in Chanhassen in the past and their work was acceptable. The Lift Station No. 2 pipe televising was budgeted for in the CIP and will be paid for under Project #SS -012. The amount budgeted for 2016 is $200,000. The Lake Susan and Saddlebrook pipe televising will be paid for under the enterprise fund for sanitary sewer. All work associated with this project is eligible for offsetting the MCES surcharge. ATTACHMENTS 1. Resolution. 2. Quotes. 3. 2016 Sanitary Sewer Televising (I /I) Project Location Maps. 4. CIP Page 81. c: Kevin Crooks, Utility Superintendent Kerry Blaisdell, Pipe Services Corporation g: \eng \public \_2016 projects \16 -02 i &i project \communication \160613_approve re- televising quote.doc CITY OF CHANHASSEN CARVER AND HENNEPIN COUNTIES, MINNESOTA DATE: June 13, 2016 . RESOLUTION NO: 2016 -XX MOTION BY: SECONDED BY: A RESOLUTION ACCEPTING QUOTES AND AWARDING CONTRACT FOR ADDITIONAL 2016 SANITARY SEWER TELEVISING PROJECT NO. 16-02 WHEREAS, pursuant to a request for quotes for additional 2016 Sanitary Sewer Televising (1/1), two quotes were received and opened. The quotes are as follows: Bidder Total Bid 1. Pipe Services Corporation $39,640.11 2. Hydro Klean $56,132.66 AND WHEREAS, Pipe Services Corporation had the lowest responsible quote with a total quote amount of $39,640.11. NOW THEREFORE, BE IT RESOLVED by the Chanhassen City Council: 1. The mayor and clerk are hereby authorized and directed to enter into a contract with Pipe Services Corporation in the name of the City of Chanhassen for additional 2016 Sanitary Sewer Televising (1/1), Project No. 16 -02, according to the plans and specifications therefore approved by the City Council and on file in the office of the city clerk. 2. The city clerk is hereby authorized and directed to return forthwith to all bidders the deposits made with their bids, except that the deposits of the successful bidder and the next lowest bidder shall be retained until a contract has been signed. Passed and adopted by the Chanhassen City Council this 13t1i day of June, 2016. ATTEST: Todd Gerhardt, City Manager YES g:\admin\resol\20161san sewer televising 061316.doc Denny Laufenburger, Mayor NO ABSENT 2016 Sanitary Sewer I &I Retelevising Quotes Bidder #2: Hydro Klean $56,132.66 142% G: \ENG \PUBLIC \_2016 PROJECTS \16 -02 I &I Project \Contract Administration \Televising Bid Tab_2.xls Engineer's Bidder #1: Estimate Pipe Services LUMP SUM TOTAL $42,447.66 $39,640.11 PERCENTAGE OF LOW BID 107% 100% Bidder #2: Hydro Klean $56,132.66 142% G: \ENG \PUBLIC \_2016 PROJECTS \16 -02 I &I Project \Contract Administration \Televising Bid Tab_2.xls Lake Susan Development i N O J co 01 M M r Cl) N N M M MQ n At/ N N }. Oa �GJV r O M M M. r M i V N N J T 92L �� £ Cl) '' Y co r A( 1pe C4 P a A r r p C4 < M M N M N N O O� T N Al N N Q Q O �leJj r n N ry� 00! ^O^ W) r T et r OD . Op IOC � � ►�, w o —� —, i,��i; suieid ,le t8 t Huron Q 9e e` 968[ ! '2 " N 9v0 4 n N co to Q ^ f0(jU015 V8 N N�9 n ? �C, N C N 0 Q o co /M INI N wp 4 QN U N �p iN 4 N` t0 OQ N 4 co T 0 N M N T f q N O A N r M - �Q N rc N ry�A O N �A et Cl) S_ \\ J N y 0 t L co Z O O L In18 4 �agaa� T� �t c T co 98p'�6 0 •~- ti T "t ~ 0 r t- o T ti 00 0 T A OA .e I 1 e� o � L 0 to 0 ti T J Jklm . ?v ramr-, N IV O T �M 1 C� • L O 0 `o ti Z\ LO 0 o � 0 T r L&O 1 =9 U'` T Capital Improvement Program City of Chanhassen, MN Project # SS -012 Project Name Inflow and Infiltration Abatement Account N1 701 -70xx -4751 Account #2 Account #3 Account #4 2016 thru 2020 Expenditures Department Sanitary Sewer Improvements Contact Paul Oehme Type Improvement Useful Life Unassigned Category Utilities Priority n/a Description I Total Project Cost: S1,900,000 This annual project includes televising, repairs and rehabilitation of existing sanitary sewer. The program also detects and eliminates points of entry of ground water and surface water into the City sanitary sewer system. Projects have been identified from the 2006 Inflow and Infiltration Report and aspects of the program are included in the annual street project. The projects were reviewed by Metropolitan Council and approved in lieu of surcharge fees. Justification City staff has identified numerous older sewer lines that are in need of repair. The City of Chanhassen pays the Metropolitan Council for sewage treatment. Those payments are based on the amount of flow generated by the City of Chanhassen. Surface water and ground water that makes its way into the system either through breaks, displaced joints, manhole covers, or private connections to the system increase the amount charged to the City for sewage disposal and increasing the load on the City's lift stations. Prier Expenditures 2016 2017 2018 2019 2020 Total 900,000 Maintenance 200,000 200,000 200,000 200,000 200,000 1,000,000 Total Total 200,000 200 ,000 200,000 200,000 200,000 1,000,000 Prior Funding Sources 2016 2017 2018 2019 2020 Total 900,000 Sewer Utility Fund 200,000 200,000 200,000 200,000 200,000 1,000,000 Total Total 200,000 200,000 200,000 200,000 200,000 1,000,000 Budget Impact/Other I The efforts may decrease operational costs, MCES fees and emergency call outs. It is also the City's intent to use connection charges to help fund for those costs. It is the City's belief that as new customers come on line those connection fees should help fund future infiltration problems. 81 FORM OF AGREEMENT BETWEEN CITY OF CHANHASSEN AND CONTRACTOR FOR 2016 SANITARY SEWER TELEVISING PROECT 16 -02 THIS AGREEMENT, made this 13th day of June, 2016, by and between the CITY OF CHANHASSEN, a Minnesota municipal corporation ( "Owner ") and PIPE SERVICES CORPORATION ( "Contractor "). Owner and Contractor, in consideration of the mutual covenants set forth herein, agree as follows: 1. CONTRACT DOCUMENTS. The following documents shall be referred to as the "Contract Documents ", all of which shall be taken together as a whole as the contract between the parties as if they were set verbatim and in full herein: A. This Agreement; B. Specifications dated May 6, 2016; C. City of Chanhassen General Conditions of the Construction Contract; D. Quote /Bid dated May 23, 2016. In the event of a conflict among the provisions of the Contract Documents, the order in which they are listed above shall control in resolving any such conflicts with Contract Document "A" having the first priority and Contract Document "D" having the last priority. 2. OBLIGATIONS OF THE CONTRACTOR. The contractor shall provide the goods, services, and perform the work in accordance with the Contract Documents. 3. CONTRACT PRICE. Owner shall pay Contractor for completion of the Work in accordance with the Contract Documents the amount of Thirty Nine Thousand Six Hundred Forty and 11 /100 ($39,640.11). 4. PAYMENT PROCEDURES. A. Contractor shall submit Applications for Payment. Applications for Payment will be processed by Engineer as provided in the General Conditions. B. Progress Payments; Retainage. Owner shall make 95% progress payments on account of the Contract Price on the basis of Contractor's Applications for Payment during performance of the Work. C. Payments to Subcontractor. 1758810 (1) Prompt Payment to Subcontractors. Pursuant to Minn. Stat. § 471.25, Subd. 4a, the Contractor must pay any subcontractor within ten (10) days of the Contractor's receipt of payment from the City for undisputed services provided by the subcontractor. The Contractor must pay interest of 1 'h percent per month or any part of a month to the Subcontractor on any undisputed amount not paid on time to the subcontractor. The minimum monthly interest penalty payment for an unpaid balance of $100.00 or more is $10.00. For an unpaid balance of less than $100.00, the Contractor shall pay the actual penalty due to the subcontractor. (2) Form IC -134 (attached) required from general contractor. Minn. Stat. § 290.92 requires that the City of Chanhassen obtain a Withholding Affidavit for Contractors, Form IC -134, before making final payments to Contractors. This form needs to be submitted by the Contractor to the Minnesota Department of Revenue for approval. The form is used to receive certification from the state that the vendor has complied with the requirement to withhold and remit state withholding taxes for employee salaries paid. D. Final Payment. Upon final completion of the Work, Owner shall pay the remainder of the Contract Price as recommended by Engineer. 5. COMPLETION DATE /LIQUIDATED DAMAGES. A. The Work must be completed and ready for final payment in accordance with the General Conditions by August 6, 2016. B. Contract and Owner recognize that time is of the essence of this Agreement and that Owner will suffer financial loss if the Work is not completed within the times specified in Paragraph 5.A. above, plus any extensions thereof allowed. The parties also recognize the delays, expense, and difficulties involved in proving in a legal or arbitration proceeding the actual loss suffered by Owner if the Work is not completed on time. Accordingly, instead of requiring any such proof, Owner and Contractor agree that as liquidated damages for delay (but not as a penalty), Contractor shall pay Owner N/A for each calendar day that expires after the time specified in Paragraph 5.A. for Completion until the Work is complete. Daily costs are based on MnDOT Table 1807 -1, "Schedule of Liquidated Damages as follows: 2 175as]vl TABLE 1807 -1 SCHEDULE OF LIQUIDATED DAMAGES Original Contract Amount Charge Per Cal. Day $) From More Than M To and Including $ 0 25,000 75 25,000 50,000 125 50,000 100,000 250 100,000 500,000 500 500,000 1,000,000 750 1,000,000 2,000,000 1,250 2,000,000 5,000,000 1,750 5,000,000 10,000,000 2,500 10,000,000 - - -- 3,000 6. CONTRACTOR'S REPRESENTATIONS. A. Contractor has examined and carefully studied the Contract Documents and other related data identified in the Contract Documents. B. Contractor has visited the Site and become familiar with and is satisfied as to the general, local, and Site conditions that may affect cost, progress, and performance of the Work. C. Contractor is familiar with and is satisfied as to all federal, state, and local Laws and Regulations that may affect cost, progress, and performance of the Work. D. Contractor has carefully studied all: (1) reports of explorations and tests of subsurface conditions at or contiguous to the Site and all drawings of physical conditions in or relating to existing surface or subsurface structures at or contiguous to the Site (except Underground Facilities) which have been identified in the General Conditions and (2) reports and drawings of a Hazardous Environmental Condition, if any, at the site. E. Contractor has obtained and carefully studied (or assumes responsibility for doing so) all additional or supplementary examinations, investigations, explorations, tests, studies, and data concerning conditions (surface, subsurface, and Underground Facilities) at or contiguous to the Site which may affect cost, progress, or performance of the Work or which relate to any aspect of the means, methods, techniques, sequences, and procedures of construction to be employed by Contractor, including any specific means, methods, techniques, sequences, and procedures of construction 175881vl expressly required by the Bidding Documents, and safety precautions and programs incident thereto. F. Contractor does not consider that any further examinations, investigations, explorations, tests, studies, or data are necessary for the performance of the Work at the Contract Price, within the Contract Times, and in accordance with the other terms and conditions of the Contract Documents. G. Contractor is aware of the general nature of work to be performed by Owner and others at the Site that relates to the Work as indicated in the Contract Documents. H. Contractor has correlated the information known to Contractor, information and observations obtained from visits to the Site, reports and drawings identified in the Contract Documents, and all additional examinations, investigations, explorations, tests, studies, and data with the Contract Documents. I. Contractor has given Engineer written notice of all conflicts, errors, ambiguities, or discrepancies that Contractor has discovered in the Contract Documents, and the written resolution thereof by Engineer is acceptable to Contractor. J. The Contract Documents are generally sufficient to indicate and convey understanding of all terms and conditions for performance and furnishing of the Work. K. Subcontracts: (1) Unless otherwise specified in the Contract Documents, the Contractor shall, upon receipt of the executed Contract Documents, submit in writing to the Owner the names of the Subcontractors proposed for the work. Subcontractors may not be changed except at the request or with the consent of the Owner. (2) The Contractor is responsible to the Owner for the acts and omissions of the Contractor's subcontractors, and of their direct and indirect employees, to the same extent as the Contractor is responsible for the acts and omissions of the Contractor's employees. (3) The Contract Documents shall not be construed as creating any contractual relation between the Owner, the Engineer, and any Subcontractor. 4 »sasiv] (4) The Contractor shall bind every Subcontractor by the terms of the Contract Documents. 7. WORKER'S COMPENSATION. The Contractor shall obtain and maintain for the duration of this Contract, statutory Worker's Compensation Insurance and Employer's Liability Insurance as required under the laws of the State of Minnesota. 8. COMPREHENSIVE GENERAL LIABILITY. Contractor shall obtain the following minimum insurance coverage and maintain it at all times throughout the life of the Contract, with the City included as an additional name insured on a primary and non- contributory basis. The Contractor shall furnish the City a certificate of insurance satisfactory to the City evidencing the required coverage: Bodily Injury: Property Damage: $2,000,000 each occurrence $2,000,000 aggregate products and completed operations $2,000,000 each occurrence $2,000,000 aggregate Contractual Liability (identifying the contract): Bodily Injury: $2,000,000 each occurrence Property Damage: $2,000,000 each occurrence $2,000,000 aggregate Personal Injury, with Employment Exclusion deleted: $2,000,000 aggregate Comprehensive Automobile Liability (owned, non - owned, hired): Bodily Injury: $2,000,000 each occurrence $2,000,000 each accident Property Damage: $2,000,000 each occurrence 9. WARRANTY. The Contractor guarantees that all new equipment warranties as specified within the quote shall be in full force and transferred to the City upon payment by the City. The Contractor shall be held responsible for any and all defects in workmanship, materials, and equipment which may develop in any part of the contracted service, and upon proper notification by the City shall immediately replace, without cost to the City, any such faulty part or parts and damage done by reason of the same in accordance with the bid specifications. 10. INDEMNITY. The Contractor agrees to indemnify and hold the City harmless from any claim made by third parties as a result of the services performed by it. In addition, the »s881vi Contractor shall reimburse the City for any cost of reasonable attorney's fees it may incur as a result of any such claims. 11. MISCELLANEOUS. A. Terms used in this Agreement have the meanings stated in the General Conditions. B. Owner and Contractor each binds itself, its partners, successors, assigns and legal representatives to the other party hereto, its partners, successors, assigns and legal representatives in respect to all covenants, agreements, and obligations contained in the Contract Documents. C. Any provision or part of the Contract Documents held to be void or unenforceable under any Law or Regulation shall be deemed stricken, and all remaining provisions shall continue to be valid and binding upon Owner and Contractor, who agree that the Contract Documents shall be reformed to replace such stricken provision or part thereof with a valid and enforceable provision that comes as close as possible to expressing the intention of the stricken provisions. D. Data Practices /Records. (1) All data created, collected, received, maintained or disseminated for any purpose in the course of this Contract is governed by the Minnesota Government Data Practices Act, Minn. Stat. Ch. 13, any other applicable state statute, or any state rules adopted to implement the act, as well as federal regulations on data privacy. (2) All books, records, documents and accounting procedures and practices to the Contractor and its subcontractors, if any, relative to this Contract are subject to examination by the City. E. Software License. If the equipment provided by the Contractor pursuant to this Contract contains software, including that which the manufacturer may have embedded into the hardware as an integral part of the equipment, the Contractor shall pay all software licensing fees. The Contractor shall also pay for all software updating fees for a period of one year following cutover. The Contractor shall have no obligation to pay for such fees thereafter. Nothing in the software license or licensing agreement shall obligate the City to pay any additional fees as a condition for continuing to use the software. F. Patented devices, materials and processes. If the Contract requires, or the Contractor desires, the use of any design, devise, material or process covered by letters, patent or copyright, trademark or trade name, the 6 175881v1 Contractor shall provide for such use by suitable legal agreement with the patentee or owner and a copy of said agreement shall be filed with the Owner. If no such agreement is made or filed as noted, the Contractor shall indemnify and hold harmless the Owner from any and all claims for infringement by reason of the use of any such patented designed, device, material or process, or any trademark or trade name or copyright in connection with the Project agreed to be performed under the Contract, and shall indemnify and defend the Owner for any costs, liability, expenses and attorney's fees that result from any such infringement G. Assignment. Neither party may assign, sublet, or transfer any interest or obligation in this Contract without the prior written consent of the other party, and then only upon such terms and conditions as both parties may agree to and set forth in writing. H. Waiver. In the particular event that either party shall at any time or times waive any breach of this Contract by the other, such waiver shall not constitute a waiver of any other or any succeeding breach of this Contract by either party, whether of the same or any other covenant, condition or obligation. Governing LawNenue. The laws of the State of Minnesota govern the interpretation of this Contract. In the event of litigation, the exclusive venue shall be in the District Court of the State of Minnesota for Carver County. J. Severability. If any provision, term or condition of this Contract is found to be or become unenforceable or invalid, it shall not affect the remaining provisions, terms and conditions of this Contract, unless such invalid or unenforceable provision, term or condition renders this Contract impossible to perform. Such remaining terms and conditions of the Contract shall continue in full force and effect and shall continue to operate as the parties' entire contract. K. Entire Agreement. This Contract represents the entire agreement of the parties and is a final, complete and all inclusive statement of the terms thereof, and supersedes and terminates any prior agreement(s), understandings or written or verbal representations made between the parties with respect thereto. L. Permits and Licenses; Rights -of -Way and Easements. The Contractor shall procure all permits and licenses, pay all charges and fees therefore, and give all notices necessary and incidental to the construction and completion of the Project. The City will obtain all necessary rights -of- way and easements. The Contractor shall not be entitled to any additional 7 17sasivi CI1 compensation for any construction delay resulting from the City's not timely obtaining rights -of -way or easements. M. If the work is delayed or the sequencing of work is altered because of the action or inaction of the Owner, the Contractor shall be allowed a time extension to complete the work but shall not be entitled to any other compensation. 117UU %JVl IMIUL, %-ILy ivialla6cl 175881v1 PIPE SER CE CORPORATION BY: Its ® DATE (MM /DDNYYY) ACORO CERTIFICATE OF LIABILITY INSURANCE 06/30/2016 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER, AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder is an ADDITIONAL INSURED, the policy(ies) must have ADDITIONAL INSURED provisions or be endorsed. If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). PRODUCER CONTACT NAME: Daniel J Lubich Daniel J Lubich PHONE (651) 779.6083 FAX G E-MAIL FBL Financial Group Inc. Ext) _ A/C No L 765C Currell Blvd Ste 240 ADDRESS: Woodbury MN 55125 INSURED BLAISDELL AND WESTLIE INC DBA PIPE SERVICE CORPORATION 16281 BASELINE AVE SHAKOPEE, MN 553799102 INSUI AFFORDING COVERAGE NAIC # INSURER A: Farm Bureau Property 8 Casualty Insurance Company 13773 INSURER 8 SUBR INSURER C POLICY EFF MM /DD/YYYY INSURER D: LIMITS _ INSURER E ❑; CPP001 6767 02/16/2016 INSURER F. rnVFRAi CERTIFICATE NUMBER: REVISION NUMBER: THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. INSR'� LTR TYPE OF INSURANCE ADDL SUBR POLICY NUMBER POLICY EFF MM /DD/YYYY POLICY EXP MM /DD/YYYY LIMITS A ',X COMMERCIAL GENERAL LIABILITY CLAIMS -MADE OCCUR ❑; CPP001 6767 02/16/2016 02/16/2017 EACH OCCURRENCE $ 1,000,000 DAMAGE 0 RENTED PREMISES Ea occurrence $ 100,000 MED EXP (Any one person) $ 5,000 PERSONAL &ADV INJURY $ 1,000,000 GENERAL AGGREGATE $ 2,000,000 GEN'L AGGREGATE LIMIT APPLIES PER: �'i ! : X PRO- POLICY'— E� �j LOC OTHER: - COMP /OP AGG $ 2,000,000 AUTOMOBILE LIABILITY A CPP0016767 02/16/2016 2/16/2017 COMBINED SINGLE LIMIT Eaaocident $ 1,000,000 BODILY INJURY (Per person) _ $ I❑�I❑ ANY AUTO '. OWNED X SCHEDULED AUTOS ONLY AUTOS BODILY INJURY (Per accident) $ PROPERTY DAMAGE Per accident $ X HIRED �X NON -OWNED - : AUTOS ONLY___ AUTOS ONLY $ A UMBRELLA LIAR _X OCCUR I❑ ❑, CU 0001202 1 02/16/2016 ^EXCESSLIAB 02/16/2017 1 EACH OCCURRENCE $ 1,000,000 _ _JI- CLAIMS-MADE1 ! 'i, AGGREGATE $ 1,000,000 $ DED X RETENTION 10,000 WORKERS COMPENSATION A AND EMPLOYERS' LIABILITY Y/ N WC 0005187 02/16/2016 ANY PROPRIETOR/PARTNER/EXECUTIVE OFFICER/MEMBER EXCLUDED? ❑N I N I A r7 (Mandatory in NH) 1 02/16/2017 X PER OTH- STATUTE ER E.L. EACH ACCIDENT $ 1,000,000 E.L. DISEASE - EA EMPLOYEE $ 1,000,000 If yes, describe under DESCRIPTION OF OPERATIONS below E.L. DISEASE - POLICY LIMIT $ 1,000,000 I DESCRIPTION OF OPERATIONS / LOCATIONS / VEHICLES (ACORD 101, Additional Remarks Schedule, may be attached if more space is required) City of Chanhassen is listed as an additional insured for General Liability. CFRTIFICATF HOI nFR CANCELLATION City Chanhassen SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE 7700 Ma rket Blvd Mahassen, EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN Chan MN 55317 Chan ACCORDANCE WITH THE POLICY PROVISIONS. AUTHORIZED REPRESENTATIVE Dan Lubich © 1988 -2016 ACORD CORPORATION. All rights reserved. ACORD 25 (2016103) The ACORD name and logo are registered marks of ACORD