Sanitary Sewer Televising for the 2017 Sanitary Sewer I/I Project No. 17-04: Approve Quote TY D -r7
CITY OF CHANIIASSEN
�l 0�
•
9 S Chanhassen is a Community for Life-Providing for Today and Planning for Tomorrow
tVy AS
MEMORANDUM
TO: Paul Oehme,Director of Public Works/City Engineer-
FROM: Stephanie Smith, Project Engineer
DATE: April 24, 2017 O , �
SUBJ: Sanitary Sewer Televising for the 2017 Sanitary Sewer UI Project No. 17-04:
Approve Quote
PROPOSED MOTION
"The City Council approves a quote for the Sanitary Sewer Televising Service for 2017 Sanitary
Sewer I/I Project No. 17-04 from Pipe Services Corporation in the amount of$37,359.93."
City Council approval requires a simple majority vote of the City Council present.
BACKGROUND
The Metropolitan Council is currently monitoring the flow of sanitary sewer from each city to determine
the amount of Inflow and Infiltration(I/I)to the Met Council's treatment plant. If the City exceeds the
allowance set by the Met Council,the City will be surcharged a fee based on the amount of flow above
the allowed amount. This project will help reduce I/I from entering the sanitary sewer system by locating
infiltration from the public system and other contributors to I/I in the City's sanitary sewer system.
DISCUSSION
Sanitary sewer televising consists of cleaning out the sanitary sewer and recording video of the lengths of
pipe in the project area. The contractor will produce a report for the City about any deficiencies observed
during the video examination of the pipes.
The information obtained from the televising will be used to plan what sanitary sewer repairs will need to
be included as part of the 2017 Sanitary Sewer I/I Project No. 17-04,the 2018 Street Reconstruction
Project and the 2019 Street Rehabilitation Project.
BIDS RECEIVED
The City of Chanhassen solicited quotes from three contractors on March 27, 2015. Three quotes were
received. The low quote for this project was from Pipe Services Corporation. This contractor has
completed work in Chanhassen in the past and their work has been acceptable.
Contactor Quote Total
Hydro Klean $ 82,320.47
Pipe Services $37,359.93
Sewer Services,Inc. $ 55,754.90
PH 952.227.1100• www.ci.chanhassen.mn.11s • FX 952.227.1110
7700 MARKET BOULEVARD • PO BOX 147 • CHANHASSEN • MINNESOTA 55317
Paul Oehme
Sanitary Sewer Televising: Approve Quote
April 24,2017
Page 2
Funding for this project has been budgeted for in the 2017 CIP, Project SS-012,and will be paid for by
the Sewer Utility Fund. The amount budgeted for 2017 is$200,000.
All work associated with this project is eligible for offsetting the MCES surcharge.
Attachments: 1. 2017 Sanitary Sewer Televising Project Location Maps
2. CIP Page
3. Resolution
c: Kevin Crooks,Utility Superintendent
g:\eng\public\_2017 projects\1 7-04 2017 sanitary sewer i&i project\communication\1 70424_cc_approve televising quote.doc
Z Q
s
N i 0 i Hl
4. M••NNNMN•MMMmMeromeN.M... ..yIMM.0NMM•,-
Z.
I
.. EUS C'
7 !4/
A
lir
U
N qµ3
O
2
,,i
Ca
8(........4„.4
8 o cv 1 c
N N co
Q G
T
N
(6
co
N N
wo.
._i ,.n
to no
= .c
4—, .I7
N .�
J L N
1—
cco I�
C 2 o
O 3 c
V)a. TOT HJ. coN
i2: 0
= xm
oi+41\ �,�
;r. ` m • . .- pP0
/ a���e? - 101
E �.A.4.....x ........./7
R°
c.
y 1-',.
�
J
Z.,
.,,,
s�'"48--..
c•
, •
U),_
C
2
5
m
U'
f6
s_ N
a U,
V) 0 0(
as 2
W on
E
v •7
.L N O 5
Tu0
4) m H
J >ro 'Cu- C
► ) y @
c
v
-z- ,71: '-...! .7 7-7,40y
V y7 Y
LN N ?S
C 7 C
iii
15. r t
b .: ^�
A
x
I. I r Ilk
fy
i1 r
...L,
= _. ,_
_ .,,
.,..
f
8J
, :,...
Z. '..::.
c'
2
7
.g. ,
VI,
. ...7.;,
3: •;i7,
:=..
. _ 4
4 2
o
... _
$, ,-- tO
11414d•iwe 4 ,c:: ,f., C
•—
mou va
uilli ...-4,.. 4 2
_ >,
., ',..,
U a
a) 0
<
a a)
CO (0 (1)
4—,
-C
to -
0 c --
_
(U '..7 •
W.)
Tu 4• . 0
a) .u)
C
.c a)
al F-
, ;. s'. '. •E
i f , . •
• t2
.. c,
5t "ci
t5
1 1
8.5
121
10
12
111
C
. 12
12,-a
4% 0 \,,,,
e/t/se j... ' ' ..].-C7".: `r
:,,-• . . '.,
:.,,,,,,,, ,_
0-t
R
-- g
,...,'^
,-:
is
.212
4,1
_
.
...,, _.
0 • A,
7'i '44
1 ...: .1.-r.,.
-.., - ($‘......
"? .
-
, = , •
IHca
^� \,.., z Q
it
L' • ..�.
� rA
• ( •
ado `Od
0' •. . i :-
ff•
/ r ajou
Aliit ,
(I)di • elel
S
E •
J •
-\\\
,m r
/ r-
:F.1-: anuany ;
ti
•r---4‹s I
to
-- \ ti, C
. C. rC
\\ !
W , OiiGGSy i n• ® ® t5
-- meq_
P
3
Q tis sCO
s
ti
w cC 65
\ z m
� N
Z ) • C N
r. (0
G`I •
$ q7 / 3 0
• � �
O f
_ •
4,innn
•
r r Q
v •
..'(//'Z'
Qv A
1.115; : •
O Irin�c 6%06
o c, r
L. 4 v _ L_
� CO
k
11111' ® , n
o>•
(] 3 A
F3 H
.
9d •
•
— -
a • >'-iiZ i i
_43 '
=
/[ T /
= -
(D •
P" NV
s (13
E -I-0 •
;25 j_ '-,
I .
‘,7, '‘; 33 ----- /
C
06)QWICZ fl3
W
ct
0
41
12
ZCZ
co
J
fz, •
co
0 '5
co
a)
Q r ___-1\ `Q m o
c
cu
0
: � co 2
O Imo.Et
o�E• •
--__________ Ilk
_ _
N ll C
13
as
A - '• imzi,
(I)
n
e
o\a
� N
M
111101111!
0
ell
C
or\IIIV
!y
'mac•!./, Z. *,
a
Capital Improvement Program 2017 thru 2021 Department Sanitary Sewer Improvements
City of Chanhassen, MN Contact Paul Oehme
Project# SS-012 Type Improvement
Useful Life Unassigned
Project Name Inflow and Infiltration Abatement
Category Utilities
Account#1 70l-70xx-4751 Account#3 Priority nit!
Account#2 Account#4
Description Total Project Cost: 52,100,000
This annual project includes televising,repairs and rehabilitation of existing sanitary sewer. The program also detects and eliminates points of
entry of ground water and surface water into the City sanitary sewer system. Projects have been identified from the 2006 Inflow and Infiltration
Report and aspects of the program are included in the annual street project. The projects were reviewed by Metropolitan Council and approved in
lieu of surcharge fees.
Justification
City staff has identified numerous older sewer lines that are in need of repair. The City of Chanhassen pays the Metropolitan Council for sewage
treatment. Those payments are based on the amount of flow generated by the City of Chanhassen. Surface water and ground water that makes its
way into the system either through breaks,displaced joints,manhole covers,or private connections to the system increase the amount charged to
the City for sewage disposal and increasing the load on the City's lift stations.
Prior Expenditures 2017 2018 2019 2020 2021 Total
1,100,000 Maintenance 200,000 200,000 200,000 200,000 200,000 1,000,000
Total Total 200,000 200,000 200,000 200,000 200,000 1,000,000
Prior Funding Sources 2017 2018 2019 2020 2021 Total
1,100,000 Sewer Utility Fund 200,000 200,000 200,000 200,000 200,000 1,000,000
Total Total 200,000 200,000 200,000 200,000 200,000 1,000,000
Budget Impact/Other
The efforts may decrease operational costs,MCES fees and emergency call outs. It is also the City's intent to use connection charges to help fund
for those costs. It is the City's belief that as new customers come on line those connection fees should help fund future infiltration problems.
79
CITY OF CHANHASSEN
CARVER AND HENNEPIN COUNTIES,MINNESOTA
DATE: April 24,2017 RESOLUTION NO: 2017-XX
MOTION BY: SECONDED BY:
A RESOLUTION APPROVING A QUOTE FOR SANITARY SEWER TELEVISING
FOR THE 2017 SANITARY SEWER INFILTRATION/INFLOW(I/I)
PROJECT NO. 17-04
WHEREAS,pursuant to a request for quotes for sanitary sewer televising for the 2017
Sanitary Sewer I/I project,three quotes were received and opened. The quotes are as follows:
Contactor lilt Quote Total
Hydro Klean $ 82,320.47
Pipe Services $ 37,359.93
Sewer Services, Inc. $ 55,754.90
AND WHEREAS,Pipe Services Corporation had the lowest responsible quote with a total
quote amount of$37,359.93.
NOW THEREFORE,BE IT RESOLVED by the Chanhassen City Council:
1. The mayor and clerk are hereby authorized and directed to enter into a contract with Pipe
Services Corporation in the name of the City of Chanhassen for sanitary sewer televising
for the 2017 Sanitary Sewer 1/I Project No. 17-04, according to the plans and specifications
therefore approved by the City Council and on file in the office of the city clerk.
2. The city clerk is hereby authorized and directed to return forthwith to all quoters the
deposits made with their bids, except that the deposits of the successful bidder and the next
lowest bidder shall be retained until a contract has been signed.
Passed and adopted by the Chanhassen City Council this 24th day of April,2017.
ATTEST:
Todd Gerhardt, City Manager Denny Laufenburger, Mayor
YES NO ABSENT
FORM OF AGREEMENT
BETWEEN CITY OF CHANHASSEN AND CONTRACTOR
FOR
SANITARY SEWER TELEVISING FOR THE 2017 SANITARY
SEWER I/I PROJECT NO. 17-04
THIS AGREEMENT, made this 24th day of April, 2017, by and between the CITY OF
CHANHASSEN, a Minnesota municipal corporation ("Owner") and PIPE SERVICES
CORPORATION ("Contractor"). Owner and Contractor, in consideration of the mutual
covenants set forth herein, agree as follows:
1. CONTRACT DOCUMENTS. The following documents shall be referred to as
the "Contract Documents", all of which shall be taken together as a whole as the contract
between the parties as if they were set verbatim and in full herein:
A. This Agreement;
B. Specifications dated April 4, 2017;
C. City of Chanhassen General Conditions of the Construction Contract;
D. Quote/Bid dated April 11, 2017.
In the event of a conflict among the provisions of the Contract Documents, the order in which
they are listed above shall control in resolving any such conflicts with Contract Document "A"
having the first priority and Contract Document "D" having the last priority.
2. OBLIGATIONS OF THE CONTRACTOR. The contractor shall provide the
goods, services, and perform the work in accordance with the Contract Documents.
3. CONTRACT PRICE. Owner shall pay Contractor for completion of the Work
in accordance with the Contract Documents the amount of Thirty Seven Thousand Three
Hundred Fifty Nine and 93/100 ($37,359.93).
4. PAYMENT PROCEDURES.
A. Contractor shall submit Applications for Payment. Applications for
Payment will be processed by Engineer as provided in the General
Conditions.
B. Progress Payments; Retainage. Owner shall make 95% progress payments
on account of the Contract Price on the basis of Contractor's Applications
for Payment during performance of the Work.
C. Payments to Subcontractor.
175881v1
(1) Prompt Payment to Subcontractors. Pursuant to Minn. Stat. §
471.25, Subd. 4a, the Contractor must pay any subcontractor
within ten (10) days of the Contractor's receipt of payment from
the City for undisputed services provided by the subcontractor.
The Contractor must pay interest of 1 '/2 percent per month or any
part of a month to the Subcontractor on any undisputed amount not
paid on time to the subcontractor. The minimum monthly interest
penalty payment for an unpaid balance of $100.00 or more is
$10.00. For an unpaid balance of less than $100.00, the Contractor
shall pay the actual penalty due to the subcontractor.
(2) Form IC -134 (attached) required from general contractor. Minn.
Stat. § 290.92 requires that the City of Chanhassen obtain a
Withholding Affidavit for Contractors, Form IC -134, before
making final payments to Contractors. This form needs to be
submitted by the Contractor to the Minnesota Department of
Revenue for approval.
The form is used to receive certification from the state that the
vendor has complied with the requirement to withhold and remit
state withholding taxes for employee salaries paid.
D. Final Payment. Upon final completion of the Work, Owner shall pay the
remainder of the Contract Price as recommended by Engineer.
5. COMPLETION DATE/LIQUIDATED DAMAGES.
A. The Work must be completed and ready for final payment in accordance
with the General Conditions by June 1, 2017.
B. Contract and Owner recognize that time is of the essence of this
Agreement and that Owner will suffer financial loss if the Work is not
completed within the times specified in Paragraph 5.A. above, plus any
extensions thereof allowed. The parties also recognize the delays,
expense, and difficulties involved in proving in a legal or arbitration
proceeding the actual loss suffered by Owner if the Work is not completed
on time. Accordingly, instead of requiring any such proof, Owner and
Contractor agree that as liquidated damages for delay (but not as a
penalty), Contractor shall pay Owner $125.00 for each calendar day
that expires after the time specified in Paragraph 5.A. for Completion until
the Work is complete.
Daily costs are based on MnDOT Table 1807-1, "Schedule of Liquidated
Damages as follows:
2
175881vI
TABLE 1807-1
SCHEDULE OF LIQUIDATED
DAMAGES
Original Contract Amount
From More Than To and Including
M M
Charge
Per Cal.
Day
M
0
25,000
75
25,000
50,000
125
50,000
100,000
250
100,000
500,000
500
500,000
1,000,000
750
1,000,000
2,000,000
1,250
2,000,000
5,000,000
1,750
5,000,000
10,000,000
2,500
10,000,000
----
3,000
6. CONTRACTOR'S REPRESENTATIONS.
A. Contractor has examined and carefully studied the Contract Documents
and other related data identified in the Contract Documents.
B. Contractor has visited the Site and become familiar with and is satisfied as
to the general, local, and Site conditions that may affect cost, progress, and
performance of the Work.
C. Contractor is familiar with and is satisfied as to all federal, state, and local
Laws and Regulations that may affect cost, progress, and performance of
the Work.
D. Contractor has carefully studied all: (1) reports of explorations and tests
of subsurface conditions at or contiguous to the Site and all drawings of
physical conditions in or relating to existing surface or subsurface
structures at or contiguous to the Site (except Underground Facilities)
which have been identified in the General Conditions and (2) reports and
drawings of a Hazardous Environmental Condition, if any, at the site.
E. Contractor has obtained and carefully studied (or assumes responsibility
for doing so) all additional or supplementary examinations, investigations,
explorations, tests, studies, and data concerning conditions (surface,
subsurface, and Underground Facilities) at or contiguous to the Site which
may affect cost, progress, or performance of the Work or which relate to
any aspect of the means, methods, techniques, sequences, and procedures
of construction to be employed by Contractor, including any specific
means, methods, techniques, sequences, and procedures of construction
»5881vi
expressly required by the Bidding Documents, and safety precautions and
programs incident thereto.
F. Contractor does not consider that any further examinations, investigations,
explorations, tests, studies, or data are necessary for the performance of
the Work at the Contract Price, within the Contract Times, and in
accordance with the other terms and conditions of the Contract
Documents.
G. Contractor is aware of the general nature of work to be performed by
Owner and others at the Site that relates to the Work as indicated in the
Contract Documents.
H. Contractor has correlated the information known to Contractor,
information and observations obtained from visits to the Site, reports and
drawings identified in the Contract Documents, and all additional
examinations, investigations, explorations, tests, studies, and data with the
Contract Documents.
Contractor has given Engineer written notice of all conflicts, errors,
ambiguities, or discrepancies that Contractor has discovered in the
Contract Documents, and the written resolution thereof by Engineer is
acceptable to Contractor.
The Contract Documents are generally sufficient to indicate and convey
understanding of all terms and conditions for performance and furnishing
of the Work.
K. Subcontracts:
(1) Unless otherwise specified in the Contract Documents, the
Contractor shall, upon receipt of the executed Contract Documents,
submit in writing to the Owner the names of the Subcontractors
proposed for the work. Subcontractors may not be changed except
at the request or with the consent of the Owner.
(2) The Contractor is responsible to the Owner for the acts and
omissions of the Contractor's subcontractors, and of their direct
and indirect employees, to the same extent as the Contractor is
responsible for the acts and omissions of the Contractor's
employees.
(3) The Contract Documents shall not be construed as creating any
contractual relation between the Owner, the Engineer, and any
Subcontractor.
0
17588 t I
(4) The Contractor shall bind every Subcontractor by the terms of the
Contract Documents.
7. WORKER'S COMPENSATION. The Contractor shall obtain and maintain for
the duration of this Contract, statutory Worker's Compensation Insurance and Employer's
Liability Insurance as required under the laws of the State of Minnesota.
8. COMPREHENSIVE GENERAL LIABILITY. Contractor shall obtain the
following minimum insurance coverage and maintain it at all times throughout the life of the
Contract, with the City included as an additional name insured on a primary and non-
contributory basis. The Contractor shall furnish the City a certificate of insurance satisfactory to
the City evidencing the required coverage:
Bodily Injury:
Property Damage:
$2,000,000 each occurrence
$2,000,000 aggregate products and
completed operations
$2,000,000 each occurrence
$2,000,000 aggregate
Contractual Liability (identifying the contract):
Bodily Injury: $2,000,000 each occurrence
Property Damage: $2,000,000 each occurrence
$2,000,000 aggregate
Personal Injury, with Employment Exclusion deleted:
$2,000,000 aggregate
Comprehensive Automobile Liability (owned, non -owned, hired):
Bodily Injury: $2,000,000 each occurrence
$2,000,000 each accident
Property Damage: $2,000,000 each occurrence
9. WARRANTY. The Contractor guarantees that all new equipment warranties as
specified within the quote shall be in full force and transferred to the City upon payment by the
City. The Contractor shall be held responsible for any and all defects in workmanship, materials,
and equipment which may develop in any part of the contracted service, and upon proper
notification by the City shall immediately replace, without cost to the City, any such faulty part
or parts and damage done by reason of the same in accordance with the bid specifications.
10. INDEMNITY. The Contractor agrees to indemnify and hold the City harmless
from any claim made by third parties as a result of the services performed by it. In addition, the
175881v1
Contractor shall reimburse the City for any cost of reasonable attorney's fees it may incur as a
result of any such claims.
11. MISCELLANEOUS.
A. Terms used in this Agreement have the meanings stated in the General
Conditions.
B. Owner and Contractor each binds itself, its partners, successors, assigns
and legal representatives to the other party hereto, its partners, successors,
assigns and legal representatives in respect to all covenants, agreements,
and obligations contained in the Contract Documents.
C. Any provision or part of the Contract Documents held to be void or
unenforceable under any Law or Regulation shall be deemed stricken, and
all remaining provisions shall continue to be valid and binding upon
Owner and Contractor, who agree that the Contract Documents shall be
reformed to replace such stricken provision or part thereof with a valid and
enforceable provision that comes as close as possible to expressing the
intention of the stricken provisions.
D. Data Practices/Records.
(1) All data created, collected, received, maintained or disseminated
for any purpose in the course of this Contract is governed by the
Minnesota Government Data Practices Act, Minn. Stat. Ch. 13, any
other applicable state statute, or any state rules adopted to
implement the act, as well as federal regulations on data privacy.
(2) All books, records, documents and accounting procedures and
practices to the Contractor and its subcontractors, if any, relative to
this Contract are subject to examination by the City.
E. Software License. If the equipment provided by the Contractor pursuant
to this Contract contains software, including that which the manufacturer
may have embedded into the hardware as an integral part of the
equipment, the Contractor shall pay all software licensing fees. The
Contractor shall also pay for all software updating fees for a period of one
year following cutover. The Contractor shall have no obligation to pay for
such fees thereafter. Nothing in the software license or licensing
agreement shall obligate the City to pay any additional fees as a condition
for continuing to use the software.
F. Patented devices, materials and processes. If the Contract requires, or the
Contractor desires, the use of any design, devise, material or process
covered by letters, patent or copyright, trademark or trade name, the
6
175881v1
Contractor shall provide for such use by suitable legal agreement with the
patentee or owner and a copy of said agreement shall be filed with the
Owner. If no such agreement is made or filed as noted, the Contractor
shall indemnify and hold harmless the Owner from any and all claims for
infringement by reason of the use of any such patented designed, device,
material or process, or any trademark or trade name or copyright in
connection with the Project agreed to be performed under the Contract,
and shall indemnify and defend the Owner for any costs, liability,
expenses and attorney's fees that result from any such infringement
G. Assignment. Neither party may assign, sublet, or transfer any interest or
obligation in this Contract without the prior written consent of the other
party, and then only upon such terms and conditions as both parties may
agree to and set forth in writing.
H. Waiver. In the particular event that either party shall at any time or times
waive any breach of this Contract by the other, such waiver shall not
constitute a waiver of any other or any succeeding breach of this Contract
by either party, whether of the same or any other covenant, condition or
obligation.
Governing LawNenue. The laws of the State of Minnesota govern the
interpretation of this Contract. In the event of litigation, the exclusive
venue shall be in the District Court of the State of Minnesota for Carver
County.
Severability. If any provision, term or condition of this Contract is found
to be or become unenforceable or invalid, it shall not affect the remaining
provisions, terms and conditions of this Contract, unless such invalid or
unenforceable provision, term or condition renders this Contract
impossible to perform. Such remaining terms and conditions of the
Contract shall continue in full force and effect and shall continue to
operate as the parties' entire contract.
K. Entire Agreement. This Contract represents the entire agreement of the
parties and is a final, complete and all inclusive statement of the terms
thereof, and supersedes and terminates any prior agreement(s),
understandings or written or verbal representations made between the
parties with respect thereto.
L. Permits and Licenses; Rights -of -Way and Easements. The Contractor
shall procure all permits and licenses, pay all charges and fees therefore,
and give all notices necessary and incidental to the construction and
completion of the Project. The City will obtain all necessary rights-of-
way and easements. The Contractor shall not be entitled to any additional
7
1758810
compensation for any construction delay resulting from the City's not
timely obtaining rights-of-way or easements.
M. If the work is delayed or the sequencing of work is altered because of the
action or inaction of the Owner, the Contractor shall be allowed a time
extension to complete the work but shall not be entitled to any other
compensation.
CITY OF CHANHASSEN
BY:
De Laufe bu er, May r
BY:
Todd Gerhardt, City Manager
1758810