The URL can be used to link to this page

Kraus-Anderson Construction Manager Contract for Civic Campus Project Document C132® – 2019 Standard Form of Agreement Between Owner and Construction Manager as Adviser Init. / AIA Document C132 – 2019. Copyright © 1973, 1980, 1992, 2009, and 2019. All rights reserved. “The American Institute of Architects,” “American Institute of Architects,” “AIA,” the AIA Logo, and “AIA Contract Documents” are trademarks of The American Institute of Architects. This document was produced at 12:12:01 ET on 08/03/2023 under Order No.3104237575 which expires on 12/12/2023, is not for resale, is licensed for one-time use only, and may only be used in accordance with the AIA Contract Documents® Terms of Service. To report copyright violations, e-mail docinfo@aiacontracts.com. User Notes: (1198159441) 1 This document has important legal consequences. Consultation with an attorney is encouraged with respect to its completion or modification. This document is intended to be used in conjunction with AIA Documents A132™–2019, Standard Form of Agreement Between Owner and Contractor, Construction Manager as Adviser Edition; A232™–2019, General Conditions of the Contract for Construction, Construction Manager as Adviser Edition; and B132™–2019, Standard Form of Agreement Between Owner and Architect, Construction Manager as Adviser Edition. AIA Document A232™–2019 is adopted in this document by reference. Do not use with other general conditions unless this document is modified. AGREEMENT made as of the 17th day of July in the year 2023 (In words, indicate day, month and year.) BETWEEN the Owner: (Name, legal status, address, and other information) City of Chanhassen 7700 Market Boulevard P.O. Box 147 Chanhassen, MN 55317 and the Construction Manager: (Name, legal status, address, and other information) Kraus-Anderson Construction Company 501 South Eighth Street Minneapolis, MN 55404 for the following Project: (Name, location, and detailed description) Chanhassen Civic Campus Project 7700 Market Boulevard Chanhassen, MN 55317 The Architect: (Name, legal status, address, and other information) BKV Group 222 North Second Street Suite 101 Minneapolis, MN 55401 The Owner and Construction Manager agree as follows. DocuSign Envelope ID: 0D3E110D-2391-4C89-863D-B3011E2F908B Init. / AIA Document C132 – 2019. Copyright © 1973, 1980, 1992, 2009, and 2019. All rights reserved. “The American Institute of Architects,” “American Institute of Architects,” “AIA,” the AIA Logo, and “AIA Contract Documents” are trademarks of The American Institute of Architects. This document was produced at 12:12:01 ET on 08/03/2023 under Order No.3104237575 which expires on 12/12/2023, is not for resale, is licensed for one-time use only, and may only be used in accordance with the AIA Contract Documents® Terms of Service. To report copyright violations, e-mail docinfo@aiacontracts.com. User Notes: (1198159441) 2 TABLE OF ARTICLES 1 INITIAL INFORMATION 2 CONSTRUCTION MANAGER’S RESPONSIBILITIES 3 SCOPE OF CONSTRUCTION MANAGER’S BASIC SERVICES 4 SUPPLEMENTAL AND ADDITIONAL SERVICES 5 OWNER’S RESPONSIBILITIES 6 COST OF THE WORK 7 COPYRIGHTS AND LICENSES 8 CLAIMS AND DISPUTES 9 TERMINATION OR SUSPENSION 10 MISCELLANEOUS PROVISIONS 11 COMPENSATION 12 SPECIAL TERMS AND CONDITIONS 13 SCOPE OF THE AGREEMENT ARTICLE 1 INITIAL INFORMATION § 1.1 This Agreement is based on the Initial Information set forth in this Section 1.1. (For each item in this section, insert the information or a statement such as "not applicable" or "unknown at time of execution.") § 1.1.1 The Owner’s program for the Project: (Insert the Owner’s program, identify documentation that establishes the Owner’s program, or state the manner in which the program will be developed.) New City Hall and Senior Center Building- Approximately 38,000 SF Plus Underground Parking New Park Pavilion Building- Approximately 4,000 SF Site Features Including New Skate Park, Pickle Ball Courts, Playground, Splash Pad, Water Feature and Event Space Demolition of Existing City Hall § 1.1.2 The Project’s physical characteristics: (Identify or describe pertinent information about the Project’s physical characteristics, such as size; location; dimensions; geotechnical reports; site boundaries; topographic surveys; traffic and utility studies; availability of public and private utilities and services; legal description of the site, etc.) See 1.1.1 § 1.1.3 The Owner’s budget for the Cost of the Work, as defined in Section 6.1: (Provide total and, if known, a line item breakdown.) $24,023,750 § 1.1.4 The Owner’s anticipated design and construction milestone dates: DocuSign Envelope ID: 0D3E110D-2391-4C89-863D-B3011E2F908B Init. / AIA Document C132 – 2019. Copyright © 1973, 1980, 1992, 2009, and 2019. All rights reserved. “The American Institute of Architects,” “American Institute of Architects,” “AIA,” the AIA Logo, and “AIA Contract Documents” are trademarks of The American Institute of Architects. This document was produced at 12:12:01 ET on 08/03/2023 under Order No.3104237575 which expires on 12/12/2023, is not for resale, is licensed for one-time use only, and may only be used in accordance with the AIA Contract Documents® Terms of Service. To report copyright violations, e-mail docinfo@aiacontracts.com. User Notes: (1198159441) 3 .1 Design phase milestone dates, if any: Schematic Design: July-September 2023 Design Development: September-October/November 2023 Construction Documents: October/November-Decenmber2023/March 2024 (separation is anticipated for multiple bid packages during CD phase) .2 Construction commencement date: Dates are per RFP response on anticipated expedited schedule. This section may be amended once final design, lead times and phasing are known. Start Date: Anticipated May 2024 .3 Substantial Completion date or dates: Dates are per RFP response on anticipated expedited schedule. This section may be amended once final design, lead times and phasing are known. Anticipated June, 2026 This schedule assumes a mid-November 2025 to mid-May 2026 pause where KA is off site .4 Other milestone dates: § 1.1.5 The Owner intends the following procurement method for the Project: (Identify method such as competitive bid or negotiated contract.) Multiple prime contracts. § 1.1.6 The Owner’s requirements for accelerated or fast-track design and construction, multiple bid packages, or phased construction are set forth below: (Identify any requirements for fast-track scheduling or phased construction and, if applicable, list number and type of bid/procurement packages.) Anticipated 2 bid packages but understand there may be up to 4. § 1.1.7 The Owner’s anticipated Sustainable Objective for the Project: (Identify and describe the Owner’s Sustainable Objective for the Project, if any.) N/A § 1.1.7.1 If the Owner identifies a Sustainable Objective, the Owner and Construction Manager shall endeavor to define the terms, conditions and services related to the Owner’s Sustainable Objective and may complete and incorporate AIA Document E235™–2019, Sustainable Projects Exhibit, Construction Manager as Adviser Edition, into this Agreement to define the terms, conditions and services related to the Owner’s Sustainable Objective. Agreement. If E235–2019 is incorporated into this Agreement, the Owner and Construction Manager shall incorporate the completed E235–2019 into the agreements with the consultants and contractors performing services or Work in any way associated with the Sustainable Objective. § 1.1.8 Other Project information: (Identify special characteristics or needs of the Project not provided elsewhere.) N/A DocuSign Envelope ID: 0D3E110D-2391-4C89-863D-B3011E2F908B Init. / AIA Document C132 – 2019. Copyright © 1973, 1980, 1992, 2009, and 2019. All rights reserved. “The American Institute of Architects,” “American Institute of Architects,” “AIA,” the AIA Logo, and “AIA Contract Documents” are trademarks of The American Institute of Architects. This document was produced at 12:12:01 ET on 08/03/2023 under Order No.3104237575 which expires on 12/12/2023, is not for resale, is licensed for one-time use only, and may only be used in accordance with the AIA Contract Documents® Terms of Service. To report copyright violations, e-mail docinfo@aiacontracts.com. User Notes: (1198159441) 4 § 1.1.9 The Owner identifies the following representative in accordance with Section 5.5: (List name, address, and other contact information.) § 1.1.10 The persons or entities, in addition to the Owner’s representative, who are required to review the Construction Manager’s submittals to the Owner are as follows: (List name, address, and other contact information.) § 1.1.11 The Owner shall retain the following consultants and Contractors: (List name, legal status, address, and other contact information.) .1 Land Surveyor: BKV Group 222 North Second Street Suite 101 Minneapolis, MN 55401 .2 Geotechnical Engineer: TBD .3 Civil Engineer: TBD .4 Contractors, as defined in Section 1.4: N/A .5 Separate Contractors, as defined in Section 1.4: N/A .6 Other, if any: (List any other consultants retained by the Owner.) Hoisington Koegler Group, Inc. 800 North Washington Avenue Minneapolis, MN 55401 DocuSign Envelope ID: 0D3E110D-2391-4C89-863D-B3011E2F908B Init. / AIA Document C132 – 2019. Copyright © 1973, 1980, 1992, 2009, and 2019. All rights reserved. “The American Institute of Architects,” “American Institute of Architects,” “AIA,” the AIA Logo, and “AIA Contract Documents” are trademarks of The American Institute of Architects. This document was produced at 12:12:01 ET on 08/03/2023 under Order No.3104237575 which expires on 12/12/2023, is not for resale, is licensed for one-time use only, and may only be used in accordance with the AIA Contract Documents® Terms of Service. To report copyright violations, e-mail docinfo@aiacontracts.com. User Notes: (1198159441) 5 § 1.1.12 The Construction Manager identifies the following representative in accordance with Section 2.5: (List name, address, and other contact information.) Dustin Phillips- Senior Project Manager Kraus-Anderson Construction Company 501 South Eighth Street Minneapolis, MN 55404 Cell: 612-419-9563 Email: dustin.phillips@krausanderson.com § 1.1.13 The Construction Manager’s staffing plan as required under Section 3.3.3 shall include: (List any specific requirements and personnel to be included in the staffing plan, if known.) N/A § 1.1.14 The Construction Manager’s consultants retained under Basic Services, if any: (List name, legal status, address, and other contact information of any consultants.) N/A § 1.1.15 The Construction Manager’s consultants retained under Supplemental Services: N/A § 1.1.16 Other Initial Information on which this Agreement is based: N/A § 1.2 The Owner and Construction Manager may rely on the Initial Information. Both parties, however, recognize that the Initial Information may materially change and, in that event, the Owner and the Construction Manager shall shall, by appropriate written agreement, appropriately adjust the Construction Manager’s services, schedule for the Construction Manager’s services, and the Construction Manager’s compensation. The Owner shall adjust the Owner’s budget for the Cost of the Work and the Owner’s anticipated design and construction milestones, as necessary, to accommodate material changes in the Initial Information. § 1.3 The parties shall agree upon Construction Manager shall assist the Owner and Architect in establishing protocols governing the transmission and use of Instruments of Service or any other information or documentation in digital form. The parties will may use AIA Document E203™–2013, Building Information Modeling and Digital Data Exhibit, to establish the protocols for the development, use, transmission, and exchange of digital data. § 1.3.1 Any use of, or reliance on, all or a portion of a building information model without agreement to protocols governing the use of, and reliance on, the information contained in the model and without having those protocols set forth in AIA Document E203™–2013, Building Information Modeling and Digital Data Exhibit, and the requisite AIA Document G202™–2013, Project Building Information Modeling Protocol Form, model, shall be at the using or relying party’s sole risk and without liability to the other party and its contractors or consultants, the authors of, or contributors to, the building information model, and each of their agents and employees. § 1.4 The term "Contractors" refers to persons or entities who perform Work under contracts with the Owner that are administered by the Construction Manager and Architect. The term "Contractors" is used to refer to such persons or entities, whether singular or plural. The term does not include the Owner’s own forces, or Separate Contractors, which are persons or entities who perform construction under separate contracts with the Owner not administered by the Construction Manager and Architect. ARTICLE 2 CONSTRUCTION MANAGER’S RESPONSIBILITIES § 2.1 The Construction Manager shall provide the services as set forth in this Agreement. DocuSign Envelope ID: 0D3E110D-2391-4C89-863D-B3011E2F908B Init. / AIA Document C132 – 2019. Copyright © 1973, 1980, 1992, 2009, and 2019. All rights reserved. “The American Institute of Architects,” “American Institute of Architects,” “AIA,” the AIA Logo, and “AIA Contract Documents” are trademarks of The American Institute of Architects. This document was produced at 12:12:01 ET on 08/03/2023 under Order No.3104237575 which expires on 12/12/2023, is not for resale, is licensed for one-time use only, and may only be used in accordance with the AIA Contract Documents® Terms of Service. To report copyright violations, e-mail docinfo@aiacontracts.com. User Notes: (1198159441) 6 § 2.2 The Construction Manager shall perform its services consistent with the skill and care ordinarily provided by construction managers practicing in the same or similar locality under the same or similar circumstances. The Construction Manager shall perform its services as expeditiously as is consistent with such skill and care and the orderly progress of the Project. § 2.3 The Construction Manager shall provide its services in conjunction with the services of an Architect as described in AIA Document B132™–2019, Standard Form of Agreement Between Owner and Architect, Construction Manager as Adviser Edition. The Construction Manager shall not be responsible for actions taken by the Architect. § 2.4 The Construction Manager shall coordinate its services with those services provided by the Owner, the Architect, the Contractors, and the Owner’s other consultants and Separate Contractors. The Construction Manager shall be entitled to rely on, and shall not be responsible for, the accuracy and completeness of services and information furnished by the Owner, the Architect, and the Owner’s other consultants and Separate Contractors. The Construction Manager shall provide prompt written notice to the Owner if the Construction Manager becomes aware of any error, omission, or inconsistency in such services or information. § 2.5 The Construction Manager shall identify a representative authorized to act on behalf of the Construction Manager with respect to the Project. § 2.6 The Construction Manager, as soon as practicable after execution of the Agreement, shall notify the Owner in writing of the names and qualifications of its proposed key staff members. Within 14 days of receipt of the names and qualifications of the Construction Manager’s proposed key staff members, the Owner may reply to the Construction Manager in writing, stating (1) whether the Owner has reasonable objection to a proposed key staff member or (2) that the Owner requires additional time to review. Failure of the Owner to reply within the 14-day period shall constitute notice of no reasonable objection. The Construction Manager shall not staff any employees on the Project to whom the Owner has made reasonable and timely objection. The Construction Manager shall not change its key staff members without the Owner’s consent, which shall not be unreasonably withheld or delayed. § 2.7 Except with the Owner’s knowledge and consent, the Construction Manager shall not engage in any activity, or accept any employment, interest or contribution that would reasonably appear to compromise the Construction Manager’s judgment with respect to this Project. § 2.8 The Construction Manager shall maintain the following insurance until termination of this Agreement. If any of the requirements set forth below are in addition to the types and limits the Construction Manager normally maintains, the Owner shall pay the Construction Manager as set forth in section 11.7. § 2.8.1 Commercial General Liability with policy limits of not less than Two Million Dollars ($ 2,000,000 ) for each occurrence and Two Million Dollars ($ 2,000,000 ) in the aggregate for bodily injury and property damage. § 2.8.2 Automobile Liability covering vehicles owned, and non-owned vehicles used, by the Construction Manager with policy limits of not less than Two Million Dollars ($ 2,000,000 ) per accident for bodily injury, death of any person, and property damage arising out of the ownership, maintenance and use of those motor vehicles, along with any other statutorily required automobile coverage. § 2.8.3 The Construction Manager may achieve the required limits and coverage for Commercial General Liability and Automobile Liability through a combination of primary and excess or umbrella liability insurance, provided such primary and excess or umbrella liability insurance policies result in the same or greater coverage as the coverages required under Sections 2.8.1 and 2.8.2, and in no event shall any excess or umbrella liability insurance provide narrower coverage than the primary policy. The excess policy shall not require the exhaustion of the underlying limits only through the actual payment by the underlying insurers. § 2.8.4 Workers’ Compensation at statutory limits and Employers Liability with policy limits not less than Five Hundred Thousand Dollars ($ 500,000 ) each accident, Five Hundred Thousand Dollars ($ 500,000 ) each employee, and Five Hundred Thousand Dollars ($ 500,000 ) policy limit. DocuSign Envelope ID: 0D3E110D-2391-4C89-863D-B3011E2F908B Init. / AIA Document C132 – 2019. Copyright © 1973, 1980, 1992, 2009, and 2019. All rights reserved. “The American Institute of Architects,” “American Institute of Architects,” “AIA,” the AIA Logo, and “AIA Contract Documents” are trademarks of The American Institute of Architects. This document was produced at 12:12:01 ET on 08/03/2023 under Order No.3104237575 which expires on 12/12/2023, is not for resale, is licensed for one-time use only, and may only be used in accordance with the AIA Contract Documents® Terms of Service. To report copyright violations, e-mail docinfo@aiacontracts.com. User Notes: (1198159441) 7 § 2.8.5 Professional Liability covering negligent acts, errors and omissions in the performance of professional services with policy limits of not less than Five Million Dollars ($ 5,000,000 ) per claim and Five Million Dollars ($ 5,000,000 ) in the aggregate. § 2.8.6 Additional Insured Obligations. To the fullest extent permitted by law, the Construction Manager shall cause the primary and excess or umbrella polices for Commercial General Liability and Automobile Liability Commercial General Liability Insurance to include the Owner as an additional insured for claims caused in whole or in part by the Construction Manager’s negligent acts or omissions. The omissions until final completion of the Construction Phase of the Project. Such additional insured coverage shall be primary and non-contributory to any of the Owner’s insurance policies and shall apply to both ongoing and completed operations.the Owner’s insurance. In the event the Construction Manager or its insurer accepts the Owner’s tender of the defense of any claim as an additional insured, the Owner shall reimburse the Construction Manager or its insurer for all attorney’s fees and costs paid or advanced as part of the Owner’s defense to the extent the Owner, or a Contractor that had a comparable duty to provide additional insured coverage to the Owner, is adjudicated to have caused the loss or damage; provided that any such reimbursement shall not exceed $100,000 in the aggregate. § 2.8.7 The Construction Manager shall provide certificates of insurance to the Owner that evidence compliance with the requirements in this Section 2.8. § 2.9 The Construction Manager shall assist the Owner, Architect, and other Project participants in establishing building information modeling and digital data protocols for the Project Project, which may be documented using AIA Document E203™–2013, Building Information Modeling and Digital Data Exhibit, to establish the protocols for the development, use, transmission, and exchange of digital data. § 2.10 A If a centralized electronic document management system will be used on the Project, and the Construction Manager shall be designated the Responsible Project Participant in section 3.5 of E203-2013, responsible for managing and maintaining the centralized electronic document management system. The centralized electronic document management system shall include all items listed in Article 3 of E203, and the following: (List any items to be included that are not listed in Article 3 of E203-2013.) § 2.11 The Construction Manager shall retain all Project related documents and information it receives, and the Owner and Architect shall have access to the documents and information. The Construction Manager shall transmit the documents and information to the Owner at final completion. ARTICLE 3 SCOPE OF CONSTRUCTION MANAGER’S BASIC SERVICES § 3.1 Definition The Construction Manager’s Basic Services consist of those described in this Article 3, and include usual and customary Preconstruction and Construction Phase Services. Services not set forth in this Article 3 are Supplemental or Additional Services. The Owner, Construction Manager, and Contractors may agree, in consultation with the Architect, for the Construction Phase to commence prior to completion of the Preconstruction Phase, in which case, both phases will proceed concurrently. § 3.2 Preconstruction Phase § 3.2.1 The Construction Manager shall review the program furnished by the Owner and any evaluation of the Owner’s program provided by the Architect, to ascertain the requirements of the Project and shall arrive at a mutual understanding of such requirements with the Owner and Architect. § 3.2.2 The Construction Manager shall provide a preliminary evaluation of the Owner’s program, schedule and construction budget requirements, each in terms of the other. § 3.2.3 The Construction Manager shall prepare, and deliver to the Owner, for the Owner’s approval, a written Construction Management Plan that includes, at a minimum, the following: (1) preliminary evaluations required in Section 3.2.2, (2) a Project schedule, (3) cost estimates, (4) recommendations for Project delivery method, and (5) Contractors’ scopes of Work. The Construction Manager shall periodically update the Construction Management Plan, for the Owner’s approval, over the course of the Project. DocuSign Envelope ID: 0D3E110D-2391-4C89-863D-B3011E2F908B Init. / AIA Document C132 – 2019. Copyright © 1973, 1980, 1992, 2009, and 2019. All rights reserved. “The American Institute of Architects,” “American Institute of Architects,” “AIA,” the AIA Logo, and “AIA Contract Documents” are trademarks of The American Institute of Architects. This document was produced at 12:12:01 ET on 08/03/2023 under Order No.3104237575 which expires on 12/12/2023, is not for resale, is licensed for one-time use only, and may only be used in accordance with the AIA Contract Documents® Terms of Service. To report copyright violations, e-mail docinfo@aiacontracts.com. User Notes: (1198159441) 8 § 3.2.4 The Construction Manager shall prepare and periodically update the Project schedule included in the Construction Management Plan for the Architect’s review and the Owner’s acceptance. The Construction Manager shall obtain the Architect’s approval for the portion of the Project schedule relating to the performance of the Architect’s services. The Project schedule shall coordinate and integrate the Construction Manager’s services, the Architect’s services, other Owner consultants’ services, and the Owner’s responsibilities and highlight items that affect the Project’s timely completion. § 3.2.5 The Construction Manager shall update the Project schedule to include the components of the Work, including phasing of construction, times of commencement and completion required of each Contractor, ordering and delivery of products, including those that must be ordered in advance of construction, obtaining the required reviews and approvals of authorities having jurisdiction over the Project, and the occupancy requirements of the Owner. § 3.2.6 Based on the preliminary design and information prepared or provided by the Architect and other Owner consultants, the Construction Manager shall prepare, for the Architect’s review and Owner’s approval, preliminary estimates of the Cost of the Work or the cost of program requirements using area, volume or similar conceptual estimating techniques, including the establishment of sufficient contingency to reasonably anticipate the development of the Project’s design documents. § 3.2.7 The Construction Manager shall review design documents during their development and advise the Owner and Architect on proposed site use and improvements, selection of materials, building systems, and equipment. The Construction Manager shall also provide recommendations to the Owner and Architect, consistent with the Project requirements, on constructability; availability of materials and labor; sequencing for phased construction; time requirements for procurement, installation and construction; and factors related to construction cost including, but not limited to, costs of alternative designs or materials, preliminary budgets, life-cycle data, and possible cost reductions. § 3.2.8 The Construction Manager shall review recommendations for systems, materials, or equipment for the impact upon cost, schedule, sequencing, constructability, and coordination among the Contractors. The Construction Manager shall discuss its findings with the Owner and the Architect, and coordinate assist the Owner and Architect with resolution, as necessary, of any such impacts. § 3.2.9 As the Architect progresses with the preparation of the Schematic Design, Design Development and Construction Documents, the Construction Manager shall prepare and update, at appropriate intervals agreed to by the Owner, Construction Manager and Architect, an estimate of the Cost of the Work with increasing detail and refinement. The Construction Manager shall include in the estimate those costs to allow for further development of the design, bidding or negotiating, price escalation, and market conditions. The estimate shall be provided for the Architect’s review and the Owner’s approval. The Construction Manager shall inform the Owner and Architect in the event that the estimate of Cost of the Work exceeds the latest approved Project budget, and make recommendations for corrective action. § 3.2.10 As the Architect progresses with the preparation of the Schematic Design, Design Development and Construction Documents, the Construction Manager shall consult with the Owner and Architect and make recommendations whenever the Construction Manager determines that the design, or details, adversely affect cost, scope, schedule, constructability, or quality of the Project. § 3.2.11 The Construction Manager shall provide recommendations and information to the Owner and Architect regarding the assignment of responsibilities for temporary Project facilities and equipment, materials and services for common use of the Contractors. The Construction Manager shall verify that such requirements and assignment of responsibilities are included in the proposed Contract Documents. § 3.2.12 The Construction Manager shall provide recommendations and information to the Owner regarding the allocation of responsibilities for safety programs among the Contractors. § 3.2.13 The Construction Manager shall provide recommendations to the Owner on the division of the Project into individual contracts for the construction of various categories of Work, including the method to be used for selecting Contractors and awarding Contracts for Construction. The Construction Manager shall review the Drawings and Specifications and make recommendations as required to provide that (1) the Work of the Contractors is coordinated, DocuSign Envelope ID: 0D3E110D-2391-4C89-863D-B3011E2F908B Init. / AIA Document C132 – 2019. Copyright © 1973, 1980, 1992, 2009, and 2019. All rights reserved. “The American Institute of Architects,” “American Institute of Architects,” “AIA,” the AIA Logo, and “AIA Contract Documents” are trademarks of The American Institute of Architects. This document was produced at 12:12:01 ET on 08/03/2023 under Order No.3104237575 which expires on 12/12/2023, is not for resale, is licensed for one-time use only, and may only be used in accordance with the AIA Contract Documents® Terms of Service. To report copyright violations, e-mail docinfo@aiacontracts.com. User Notes: (1198159441) 9 (2) all requirements for the Project are assigned to the appropriate Contract, (3) the likelihood of jurisdictional disputes is minimized, and (4) proper coordination is provided for phased construction. § 3.2.14 The Construction Manager shall make recommendations about, and coordinate the ordering and delivery of, materials in support of the schedule, including those that must be ordered in advance of construction. § 3.2.15 The Construction Manager shall assist the Owner in selecting, retaining, and coordinating the professional services of surveyors, geotechnical engineers, special consultants, and construction materials testing required for the Project. § 3.2.16 The Construction Manager shall provide an analysis of the types and quantities of labor required for the Project and review the availability of appropriate categories of labor required for critical phases. The Construction Manager shall make recommendations for actions designed to minimize adverse effects of labor shortages. § 3.2.17 The Construction Manager shall assist the Owner in obtaining information regarding applicable requirements for equal employment opportunity programs, and other programs as may be required by governmental and quasi- governmental authorities for inclusion in the Contract Documents. § 3.2.18 Following the Owner’s approval of the Drawings and Specifications, the Construction Manager shall update and submit the latest estimate of the Cost of the Work and the Project schedule for the Architect’s review and the Owner’s approval. § 3.2.19 The Construction Manager, in consultation with the Owner, shall develop bidders’ interest in the Project and establish bidding schedules. The Construction Manager shall assist the Owner and the Architect with the development of the Bidding Documents, which consist of bidding requirements and proposed Contract Documents. The Construction Manager, with the assistance of the Architect, shall issue Bidding Documents to bidders and conduct pre-bid conferences with prospective bidders. The Construction Manager shall issue the current Project schedule with each set of Bidding Documents. The Construction Manager shall assist the Architect with regard to questions from bidders and with the issuance of addenda. § 3.2.20 The Construction Manager shall submit a list of prospective bidders for the Architect’s review and the Owner’s approval. § 3.2.21 The Construction Manager, with the assistance of the Architect, shall review bids, and prepare bid analyses, and make recommendations to the Owner for the Owner’s award of Contracts for Construction or rejection of bids. § 3.2.22 The Construction Manager, with the assistance of the Architect, shall assist the Owner in preparing Contracts for Construction. The Construction Manager shall advise the Owner on the acceptability of Subcontractors and material suppliers proposed by Contractors. The Owner will review and approve contracts consistent with the Owner’s approval process. § 3.2.23 The Construction Manager shall assist the Owner in obtaining building permits and special permits for permanent improvements, except for permits required to be obtained directly by the Contractors. The Construction Manager shall verify that the Owner has paid applicable fees and assessments. The Construction Manager shall assist the Owner and Architect in connection with the Owner’s responsibility for filing documents required for the approvals of governmental authorities having jurisdiction over the Project. § 3.2.24 If the Owner identified a Sustainable Objective in Article 1, the Construction Manager shall fulfill its Preconstruction Phase responsibilities as required in AIA Document E235™–2019, Sustainable Projects Exhibit, Construction Manager as Adviser Edition, attached to this Agreement.per the agreed-upon terms, conditions and services related to the Owner’s Sustainable Objective. § 3.3 Construction Phase § 3.3.1 The Construction Manager shall provide on-site administration of the Contracts for Construction in cooperation with the Architect as set forth below and in AIA Document A232™–2019, General Conditions of the Contract for Construction, Construction Manager as Adviser Edition. If the Owner and Contractor modify AIA DocuSign Envelope ID: 0D3E110D-2391-4C89-863D-B3011E2F908B Init. / AIA Document C132 – 2019. Copyright © 1973, 1980, 1992, 2009, and 2019. All rights reserved. “The American Institute of Architects,” “American Institute of Architects,” “AIA,” the AIA Logo, and “AIA Contract Documents” are trademarks of The American Institute of Architects. This document was produced at 12:12:01 ET on 08/03/2023 under Order No.3104237575 which expires on 12/12/2023, is not for resale, is licensed for one-time use only, and may only be used in accordance with the AIA Contract Documents® Terms of Service. To report copyright violations, e-mail docinfo@aiacontracts.com. User Notes: (1198159441) 10 Document A232–2019, those modifications shall not affect the Construction Manager’s services under this Agreement unless the Owner and the Construction Manager amend this Agreement. § 3.3.2 Subject to Section 4.2 and except as provided in Section 3.3.30, the Construction Manager’s responsibility to provide Construction Phase Services commences with the award of the initial Contract for Construction and terminates on the date the Architect issues the final Certificate for Payment. § 3.3.3 The Construction Manager shall provide a staffing plan to include one or more representatives who shall be in attendance at the Project site whenever the Work is being performed. § 3.3.4 The Construction Manager shall provide administrative, management and related services to coordinate scheduled activities and responsibilities of the Contractors with each other and with those of the Construction Manager, the Owner and the Architect. The Construction Manager shall coordinate the activities of the Contractors in accordance with the latest approved Project schedule and the Contract Documents. § 3.3.5 The Construction Manager shall review and analyze the construction schedules provided by the Contractors to update the Project schedule, incorporating the activities of the Owner, Architect, and Contractors on the Project, including activity sequences and durations, allocation of labor and materials, processing of Shop Drawings, Product Data and Samples, and delivery and procurement of products, including those that must be ordered in advance of construction. The Project schedule shall include the Owner’s occupancy requirements showing portions of the Project having occupancy priority. The Construction Manager shall update and reissue the Project schedule as required to show current conditions. If an update indicates that the previously approved Project schedule may not be met, the Construction Manager shall recommend corrective action to the Owner and Architect. § 3.3.6 The Construction Manager shall schedule and conduct meetings to discuss matters such as procedures, progress, coordination, and scheduling of the Work, and to develop solutions to issues identified. The Construction Manager shall prepare and promptly distribute minutes to the Owner, Architect and Contractors. § 3.3.7 In accordance with the Contract Documents and the latest approved Project schedule, and utilizing information from the Contractors, the Construction Manager shall review, analyze, schedule and coordinate the overall sequence of construction and assignment of space in areas where the Contractors are performing Work. § 3.3.8 The Construction Manager shall coordinate all tests and inspections required by the Contract Documents or governmental authorities, observe the on-site testing and inspections, and arrange for the delivery of test and inspection reports to the Owner and Architect. § 3.3.9 The Construction Manager shall endeavor to obtain satisfactory performance from each of the Contractors. The Construction Manager shall recommend courses of action to the Owner when requirements of a Contract are not being fulfilled. § 3.3.10 The Construction Manager shall monitor and evaluate actual costs for activities in progress and estimates for uncompleted tasks and advise the Owner and Architect as to variances between actual costs and budgeted or estimated costs. If a Contractor is required to submit a Control Estimate, the Construction Manager shall meet with the Owner and Contractor to review the Control Estimate. The Construction Manager shall promptly notify the Contractor if there are any inconsistencies or inaccuracies in the information presented. The Construction Manager shall also report the Contractor’s cost control information to the Owner. § 3.3.11 The Construction Manager shall develop cash flow reports and forecasts for the Project and include them in the Construction Manager’s progress reports. § 3.3.12 The Construction Manager shall maintain accounting records on authorized Work performed under unit costs, additional Work performed on the basis of actual costs of labor and materials, and other Work requiring accounting records. § 3.3.12.1 The Construction Manager shall develop and implement procedures for the review and processing of Applications for Payment by Contractors for progress and final payments. DocuSign Envelope ID: 0D3E110D-2391-4C89-863D-B3011E2F908B Init. / AIA Document C132 – 2019. Copyright © 1973, 1980, 1992, 2009, and 2019. All rights reserved. “The American Institute of Architects,” “American Institute of Architects,” “AIA,” the AIA Logo, and “AIA Contract Documents” are trademarks of The American Institute of Architects. This document was produced at 12:12:01 ET on 08/03/2023 under Order No.3104237575 which expires on 12/12/2023, is not for resale, is licensed for one-time use only, and may only be used in accordance with the AIA Contract Documents® Terms of Service. To report copyright violations, e-mail docinfo@aiacontracts.com. User Notes: (1198159441) 11 § 3.3.12.2 Not more frequently than monthly, the Construction Manager shall review and certify the amounts due the respective Contractors as follows: .1 Where there is only one Contractor responsible for performing the Work, the Construction Manager shall, within seven days after the Construction Manager receives the Contractor’s Application for Payment, review the Application, certify the amount the Construction Manager determines is due the Contractor, and forward the Contractor’s Application and Certificate for Payment to the Architect. .2 Where there is more than one Contractor responsible for performing different portions of the Project, the Construction Manager shall, within seven days after the Construction Manager receives each Contractor’s Application for Payment: (1) review the Applications and certify the amount the Construction Manager determines is due each Contractor; (2) prepare a Summary of Contractors’ Applications for Payment by summarizing information from each Contractor’s Application for Payment; (3) prepare a Project Application and Certificate for Payment; (4) certify the total amount the Construction Manager determines is due all Contractors collectively; and (5) forward the Summary of Contractors’ Applications for Payment and Project Application and Certificate for Payment to the Architect. § 3.3.12.3 The Construction Manager’s certification for payment shall constitute a representation to the Owner, based on the Construction Manager’s evaluations of the Work and on the data comprising the Contractors’ Applications for Payment, that, to the best of the Construction Manager’s knowledge, information and belief, the Work has progressed to the point indicated, the quality of the Work is in accordance with the Contract Documents, and the Contractors are entitled to payment in the amount certified. The foregoing representations are subject to (1) an evaluation of the Work for conformance with the Contract Documents upon Substantial Completion; (2) results of subsequent tests and inspections; (3) correction of minor deviations from the Contract Documents prior to completion; and (4) specific qualifications expressed by the Construction Manager. The issuance of a Certificate for Payment shall further constitute a recommendation to the Architect and Owner that the Contractor be paid the amount certified. § 3.3.12.4 The certification of an Application for Payment or a Project Application for Payment by the Construction Manager shall not be a representation that the Construction Manager has (1) made exhaustive or continuous on-site inspections to check the quality or quantity of the Work; (2) reviewed construction means, methods, techniques, procedures, or sequences for a Contractor’s own Work; (3) reviewed copies of requisitions received from Subcontractors and suppliers and other data requested by the Owner to substantiate each Contractor’s right to payment; or (4) ascertained how or for what purpose that Contractor has used money previously paid on account of the Contract Sum. § 3.3.13 The Construction Manager shall obtain and review the safety programs developed by each Contractor solely and exclusively for purposes of coordinating the safety programs with those of the other Contractors and for making recommendations for any additional safety measures to be considered in the Work of the Contractors. The Construction Manager’s responsibilities for coordination of safety programs shall not extend to direct control over or charge of the acts or omissions of the Contractors, Subcontractors, agents or employees of the Contractors or Subcontractors, or any other persons performing portions of the Work and not directly employed by the Construction Manager. § 3.3.14 The Construction Manager shall determine in general that the Work of each Contractor is being performed in accordance with the requirements of the Contract Documents and notify the Owner, Contractor and Architect of defects and deficiencies in the Work. The Construction Manager shall have the authority to reject Work that does not conform to the Contract Documents and shall notify the Architect about the rejection. The failure of the Construction Manager to reject Work shall not constitute acceptance of the Work. The Construction Manager shall record any rejection of Work in its daily log and include information regarding the rejected Work in its progress reports to the Architect and Owner pursuant to Section 3.3.22.1. Upon written authorization from the Owner, the Construction Manager may require and make arrangements for additional inspection or testing of the Work in accordance with the provisions of the Contract Documents, whether or not the Work is fabricated, installed or completed, and the Construction Manager shall give timely notice to the Architect of when and where the tests and inspections are to be made so that the Architect may be present for such procedures. § 3.3.15 The Construction Manager shall advise and consult with the Owner and Architect during the performance of its Construction Phase Services. The Construction Manager shall have authority to act on behalf of the Owner only to the extent provided in this Agreement. The Construction Manager shall not have control over, charge of, or DocuSign Envelope ID: 0D3E110D-2391-4C89-863D-B3011E2F908B Init. / AIA Document C132 – 2019. Copyright © 1973, 1980, 1992, 2009, and 2019. All rights reserved. “The American Institute of Architects,” “American Institute of Architects,” “AIA,” the AIA Logo, and “AIA Contract Documents” are trademarks of The American Institute of Architects. This document was produced at 12:12:01 ET on 08/03/2023 under Order No.3104237575 which expires on 12/12/2023, is not for resale, is licensed for one-time use only, and may only be used in accordance with the AIA Contract Documents® Terms of Service. To report copyright violations, e-mail docinfo@aiacontracts.com. User Notes: (1198159441) 12 responsibility for the construction means, methods, techniques, sequences or procedures, or for safety precautions and programs in connection with the Work of each of the Contractors, since these are solely the Contractor’s rights and responsibilities under the Contract Documents. The Construction Manager shall not be responsible for a Contractor’s failure to perform the Work in accordance with the requirements of the Contract Documents. The Construction Manager shall be responsible to the Owner for the Construction Manager’s negligent acts or omissions, but shall not have control over or charge of, and shall not be responsible for, acts or omissions of the Contractors, Subcontractors, or their agents or employees, or any other persons or entities performing portions of the Work. § 3.3.16 The Construction Manager shall transmit to the Architect requests for interpretations, and requests for information of the meaning and intent of the Drawings and Specifications, and provide its written recommendation. Specifications. The Construction Manager shall assist in the resolution of questions that may arise. § 3.3.17 The Construction Manager shall review requests for changes, assist in negotiating Contractors’ proposals, submit recommendations to the Architect and Owner, and, if the proposed changes are accepted or required by the Owner, prepare Change Orders or Construction Change Directives that incorporate the Architect’s modifications to the Contract Documents. § 3.3.18 The Construction Manager shall assist the Initial Decision Maker in the review, evaluation and documentation of Claims, subject to Section 4.2.2.7. § 3.3.19 Utilizing the submittal schedules provided by each Contractor, the Construction Manager shall prepare, and revise as necessary, a Project submittal schedule incorporating information from the Owner, Owner’s consultants, Owner’s Separate Contractors and vendors, governmental agencies, and participants in the Project under the management of the Construction Manager. The Project submittal schedule and any revisions shall be submitted to the Architect for approval. § 3.3.20 The Construction Manager shall promptly review all Shop Drawings, Product Data, Samples, and other submittals from the Contractors for compliance with the submittal requirements of the Contract, coordinate submittals with information contained in related documents, and transmit to the Architect those that the Construction Manager recommends for approval. The Construction Manager’s actions shall be taken in accordance with the Project submittal schedule approved by the Architect, or in the absence of an approved Project submittal schedule, with such reasonable promptness as to cause no delay in the Work or in the activities of the Contractors, the Owner, or the Architect. § 3.3.20.1 If professional design services or certifications by a design professional related to systems, materials, or equipment are specifically required of the Contractors by the Contract Documents, the Construction Manager shall review those submittals for sequencing, constructability, and coordination impacts on the other Contractors. The Construction Manager shall discuss its findings with the Owner and the Architect, and coordinate assist the Owner and the Architect with resolution, as necessary, of any such impacts. § 3.3.21 The Construction Manager shall keep a daily log containing a record of weather, each Contractor’s Work on the site, number of workers, identification of equipment, Work accomplished, problems encountered, and other similar relevant data as the Owner may require. § 3.3.21.1 The Construction Manager shall collect, review for accuracy, and compile the Contractors’ daily logs; and include them in the Construction Manager’s reports prepared and submitted in accordance with section 3.3.21.2. § 3.3.21.2 The Construction Manager shall record the progress of the Project. On a monthly basis, or otherwise as agreed to by the Owner, the Construction Manager shall submit written progress reports to the Owner and Architect, showing percentages of completion and other information identified below: .1 Work completed for the period; .2 Project schedule status; .3 Submittal schedule and status report, including a summary of remaining and outstanding submittals; .4 Request for information, Change Order, and Construction Change Directive status reports; .5 Tests and inspection reports; .6 Status report of nonconforming and rejected Work; .7 Daily logs; .8 Summary of all Contractors’ Applications for Payment; DocuSign Envelope ID: 0D3E110D-2391-4C89-863D-B3011E2F908B Init. / AIA Document C132 – 2019. Copyright © 1973, 1980, 1992, 2009, and 2019. All rights reserved. “The American Institute of Architects,” “American Institute of Architects,” “AIA,” the AIA Logo, and “AIA Contract Documents” are trademarks of The American Institute of Architects. This document was produced at 12:12:01 ET on 08/03/2023 under Order No.3104237575 which expires on 12/12/2023, is not for resale, is licensed for one-time use only, and may only be used in accordance with the AIA Contract Documents® Terms of Service. To report copyright violations, e-mail docinfo@aiacontracts.com. User Notes: (1198159441) 13 .9 Cumulative total of the Cost of the Work to date including the Construction Manager’s compensation and reimbursable expenses at the job site, if any; .10 Cash-flow and forecast reports; .11 Photographs to document the progress of the Project; .12 Status reports on permits and approvals of authorities having jurisdiction; and .13 Any other items the Owner may require: § 3.3.21.3 In addition, for Projects constructed on the basis of the Cost of the Work, the Construction Manager shall include the following additional information in its progress reports: .1 Contractors’ work force reports; .2 Equipment utilization report; .3 Cost summary, comparing actual costs to updated cost estimates; and .4 Any other items as the Owner may require: § 3.3.22 Utilizing the documents provided by the Contractors, the Construction Manager shall make available, at the Project site, the Contract Documents, including Change Orders, Construction Change Directives, and other Modifications, in good order and marked currently to indicate field changes and selections made during construction, and the approved Shop Drawings, Product Data, Samples, and similar required submittals. These shall be in electronic form or paper copy, available to the Owner, Architect, and Contractors. Upon completion of the Project, the Construction Manager shall deliver them to the Owner. § 3.3.23 The Construction Manager shall arrange for the delivery, storage, protection and security of Owner-purchased materials, systems and equipment that are a part of the Project until such items are incorporated into the Work. § 3.3.24 With the Owner’s maintenance personnel, the Construction Manager shall observe the Contractors’ final testing and start-up of utilities, operational systems and equipment and observe any commissioning as the Contract Documents may require. § 3.3.25 When the Construction Manager considers each Contractor’s Work or a designated portion thereof substantially complete, the Construction Manager shall, jointly with that Contractor, prepare for the Architect a list of incomplete or unsatisfactory items and a schedule for their completion. The Construction Manager shall assist the Architect in conducting inspections to determine whether the Work or designated portion thereof is substantially complete. § 3.3.26 When the Work of all of the Contractors, or designated portion thereof, is substantially complete, the Construction Manager shall prepare, and the Construction Manager and Architect shall execute, a Certificate of Substantial Completion. The Construction Manager shall submit the executed Certificate to the Owner and Contractors. The Construction Manager shall coordinate the correction and completion of the Work. Following issuance of a Certificate of Substantial Completion of the Work or a designated portion thereof, the Construction Manager shall perform an inspection to confirm the completion of the Work of the Contractors and make recommendations to the Architect when the Work of all of the Contractors is ready for final inspection. The Construction Manager shall assist the Architect in conducting the final inspection. § 3.3.27 The Construction Manager shall forward to the Owner, with a copy to the Architect, the following information received from the Contractors: (1) certificates of insurance ; (2) consent of surety or sureties, if any, to reduction in or partial release of retainage or the making of final payment; (3) affidavits, receipts, releases and waivers of liens or bonds indemnifying the Owner against liens; and (4) any other documentation required of the Contractors under the Contract Documents, including warranties and similar submittals. § 3.3.28 The Construction Manager shall coordinate receipt, and delivery to the Owner, of other items provided by the Contractors, such as keys, manuals, and record drawings. The Construction Manager shall forward to the Architect a DocuSign Envelope ID: 0D3E110D-2391-4C89-863D-B3011E2F908B Init. / AIA Document C132 – 2019. Copyright © 1973, 1980, 1992, 2009, and 2019. All rights reserved. “The American Institute of Architects,” “American Institute of Architects,” “AIA,” the AIA Logo, and “AIA Contract Documents” are trademarks of The American Institute of Architects. This document was produced at 12:12:01 ET on 08/03/2023 under Order No.3104237575 which expires on 12/12/2023, is not for resale, is licensed for one-time use only, and may only be used in accordance with the AIA Contract Documents® Terms of Service. To report copyright violations, e-mail docinfo@aiacontracts.com. User Notes: (1198159441) 14 final Project Application for Payment and Project Certificate for Payment, or a final Application for Payment and final Certificate for Payment, upon the Contractors’ compliance with the requirements of the Contract Documents. § 3.3.29 Duties, responsibilities and limitations of authority of the Construction Manager as set forth in the Contract Documents shall not be restricted, modified or extended without written consent of the Owner, Construction Manager, Architect, and Contractors. Owner and Construction Manager. Consent shall not be unreasonably withheld. § 3.3.30 Upon request of the Owner, and prior to the expiration of one year from the date of Substantial Completion, the Construction Manager shall, without additional compensation, conduct a meeting with the Owner and Architect to review the facility operations and performance. ARTICLE 4 SUPPLEMENTAL AND ADDITIONAL SERVICES § 4.1 Supplemental Services § 4.1.1 The services listed below are not included in Basic Services but may be required for the Project. The Construction Manager shall provide the listed Supplemental Services only if specifically designated in the table below as the Construction Manager’s responsibility, and the Owner shall compensate the Construction Manager as provided in Section 11.2. Unless otherwise specifically addressed in this Agreement, if neither the Owner nor the Construction Manager is designated, the parties agree that the listed Supplemental Service is not being provided for the Project. (Designate the Construction Manager’s Supplemental Services and the Owner’s Supplemental Services required for the Project by indicating whether the Construction Manager or Owner shall be responsible for providing the identified Supplemental Service. Insert a description of the Supplemental Services in Section 4.1.2 below or attach the description of services as an exhibit to this Agreement.) Supplemental Services Responsibility (Construction Manager, Owner or not provided) § 4.1.1.1 Measured drawings Owner § 4.1.1.2 Tenant-related services Owner, if required § 4.1.1.3 Commissioning Owner, if required § 4.1.1.4 Development of a commissioning plan Owner, if required § 4.1.1.5 Sustainable Project Services pursuant to Section 4.1.3 N/A § 4.1.1.6 Furniture, furnishings and equipment delivery, and installation coordination Owner § 4.1.1.7 Furniture, furnishings and equipment procurement assistance N/A § 4.1.1.8 Assistance with site selection N/A § 4.1.1.9 Assistance with selection of the Architect Owner § 4.1.1.10 Furnish land survey Owner, if required § 4.1.1.11 Furnish geotechnical engineering services Owner § 4.1.1.12 Provide insurance advice Owner, if required § 4.1.1.13 Provide supplemental Project risk analysis and mitigation strategies Owner, if required § 4.1.1.14 Stakeholder relationships management N/A § 4.1.1.15 Owner moving coordination N/A § 4.1.1.16 Coordination of Owner’s Separate Contractors Owner, if required § 4.1.1.17 Other Supplemental Services N/A § 4.1.2 Description of Supplemental Services § 4.1.2.1 A description of each Supplemental Service identified in Section 4.1.1 as the Construction Manager’s responsibility is provided below. (Describe in detail the Construction Manager’s Supplemental Services identified in Section 4.1.1 or, if set forth in an exhibit, identify the exhibit.) DocuSign Envelope ID: 0D3E110D-2391-4C89-863D-B3011E2F908B Init. / AIA Document C132 – 2019. Copyright © 1973, 1980, 1992, 2009, and 2019. All rights reserved. “The American Institute of Architects,” “American Institute of Architects,” “AIA,” the AIA Logo, and “AIA Contract Documents” are trademarks of The American Institute of Architects. This document was produced at 12:12:01 ET on 08/03/2023 under Order No.3104237575 which expires on 12/12/2023, is not for resale, is licensed for one-time use only, and may only be used in accordance with the AIA Contract Documents® Terms of Service. To report copyright violations, e-mail docinfo@aiacontracts.com. User Notes: (1198159441) 15 § 4.1.2.2 A description of each Supplemental Service identified in Section 4.1.1 as the Owner’s responsibility is provided below. (Describe in detail the Owner’s Supplemental Services identified in Section 4.1.1 or, if set forth in an exhibit, identify the exhibit.) § 4.1.3 If the Owner identified a Sustainable Objective in Article 1, the Construction Manager shall provide, as a Supplemental Service, the Sustainability Services required in AIA Document E235™–2019, Sustainable Projects Exhibit, Construction Manager as Adviser Edition, attached to this Agreement. per the agreed-upon terms, conditions and services related to the Owner’s Sustainable Objective. The Owner shall compensate the Construction Manager as provided in Section 11.2. § 4.2 Construction Manager’s Additional Services § 4.2.1 The Construction Manager may provide Additional Services after execution of this Agreement, without invalidating this Agreement. Except for services to the extent services are required due to the fault of the Construction Manager, any Additional Services provided in accordance with this Section 4.2 shall entitle the Construction Manager to compensation pursuant to Section 11.3. § 4.2.2 Upon recognizing the need to perform the following Additional Services, the Construction Manager shall notify the Owner with reasonable promptness and explain the facts and circumstances giving rise to the need. The Construction Manager shall not proceed to provide the following Additional Services until the Construction Manager receives the Owner’s written authorization: .1 Services necessitated by a change in the Initial Information, previous instructions or approvals given by the Owner, or a material change in the Project including size, quality, complexity, the Owner’s schedule or budget for Cost of the Work, or procurement or delivery method, or bid packages in addition to those listed in Section 1.1.6. Services necessitated by sections 6.4 and 6.6 shall not be considered additional services; .2 Services necessitated by the enactment or revision of codes, laws, regulations or official interpretations after the date of this Agreement; .3 Services necessitated by decisions of the Owner not rendered in a timely manner or any other failure of performance on the part of the Owner or the Owner’s other consultants or contractors; .4 Preparation of documentation for alternate bid or proposal requests proposed by the Owner; .5 Preparation for, and attendance at, a public presentation, meeting or hearing; .6 Preparation for, and attendance at, a dispute resolution proceeding or legal proceeding, except where the Construction Manager is party thereto; .7 Consultation concerning replacement of Work resulting from fire or other cause during construction and furnishing services required in connection with the replacement of such Work; or .8 Assistance to the Initial Decision Maker. § 4.2.3 To avoid delay in the Construction Phase, the Construction Manager shall provide the following Additional Services, notify the Owner with reasonable promptness, and explain the facts and circumstances giving rise to the need. If, upon receipt of the Construction Manager’s notice, the Owner determines that all or parts of the services are not required, the Owner shall give prompt written notice to the Construction Manager of the Owner’s determination. The Owner shall compensate the Construction Manager for the services provided prior to the Construction Manager’s receipt of the Owner’s notice: .1 Providing assistance to the Initial Decision Maker in evaluating an extensive number of Claims submitted by a Contractor or others in connection with the Work. .2 Services required in an emergency to coordinate the activities of a Contractor or Contractors in the event of risk of personal injury or serious property damage, consistent with Section 3.3.15. § 4.2.4 Except for services required under Section 3.3.30, Construction Phase Services provided more than 60 days after (1) the date of Substantial Completion of the Work, or (2) the anticipated date of Substantial Completion identified in the Initial Information, whichever is earlier, shall be compensated as Additional Services to the extent the Construction Manager incurs additional cost in providing those Construction Phase Services. DocuSign Envelope ID: 0D3E110D-2391-4C89-863D-B3011E2F908B Init. / AIA Document C132 – 2019. Copyright © 1973, 1980, 1992, 2009, and 2019. All rights reserved. “The American Institute of Architects,” “American Institute of Architects,” “AIA,” the AIA Logo, and “AIA Contract Documents” are trademarks of The American Institute of Architects. This document was produced at 12:12:01 ET on 08/03/2023 under Order No.3104237575 which expires on 12/12/2023, is not for resale, is licensed for one-time use only, and may only be used in accordance with the AIA Contract Documents® Terms of Service. To report copyright violations, e-mail docinfo@aiacontracts.com. User Notes: (1198159441) 16 § 4.2.5 If the services covered by this Agreement have not been completed within ( ) ten (10) months of the date of this Agreement, through no fault of the Construction Manager, extension of the Construction Manager’s services beyond that time shall be compensated as Additional Services. ARTICLE 5 OWNER’S RESPONSIBILITIES § 5.1 Unless otherwise provided for under this Agreement, the Owner shall provide information in a timely manner regarding requirements for and limitations on the Project, including a written program, which shall set forth the Owner’s objectives; schedule; constraints and criteria; special equipment; systems; and site requirements. § 5.2 The Owner shall establish the Owner’s budget for the Project, including (1) the budget for the Cost of the Work as defined in Section 6.1; (2) the Owner’s other costs; and (3) reasonable contingencies related to all of these costs. The Owner shall update the Owner’s budget for the Project as necessary throughout the duration of the Project until final completion. If the Owner significantly increases or decreases the Owner’s budget for the Cost of the Work, the Owner shall notify the Construction Manager and Architect. The Owner and the Architect, in consultation with the Construction Manager, shall thereafter agree to a corresponding change in the Project’s scope and quality. § 5.3 The Owner acknowledges that accelerated, phased, or fast-track design and construction provides a benefit, but also carries with it the risk of additional costs. If the Owner selects accelerated, phased or fast-track scheduling, the Owner agrees to include in the budget for the Project sufficient contingencies to cover such costs. § 5.4 The Owner shall retain an Architect to provide services, duties and responsibilities as described in AIA Document B132–2019, Standard Form of Agreement Between Owner and Architect, Construction Manager as Adviser Edition. The Owner shall provide the Construction Manager with a copy of the scope of services in the agreement executed between the Owner and Architect, and any further modifications to the Architect’s scope of services in the agreement. § 5.5 The Owner shall identify a representative authorized to act on the Owner’s behalf with respect to the Project. The Owner shall render decisions pertaining to documents the Construction Manager submits in a timely manner in order to avoid unreasonable delay in the orderly and sequential progress of the Construction Manager’s services. § 5.6 Unless otherwise required by this Agreement to be provided by the Construction Manager, the Owner shall furnish surveys to describe physical characteristics, legal limitations and utility locations for the site of the Project, and a written legal description of the site. The surveys and legal information shall include, as applicable, grades and lines of streets, alleys, pavements and adjoining property and structures; designated wetlands; adjacent drainage; rights-of-way, restrictions, easements, encroachments, zoning, deed restrictions, boundaries, and contours of the site; locations, dimensions, and other necessary data with respect to existing buildings, other improvements and trees; and information concerning available utility services and lines, both public and private, above and below grade, including inverts and depths. All the information on the survey shall be referenced to a Project benchmark. § 5.7 Unless otherwise required by this Agreement to be provided by the Construction Manager, the Owner shall furnish services of geotechnical engineers, which may include test borings, test pits, determinations of soil bearing values, percolation tests, evaluations of hazardous materials, seismic evaluation, ground corrosion tests and resistivity tests, including necessary operations for anticipating subsoil conditions, with written reports and appropriate recommendations. § 5.8 The Owner shall provide the Supplemental Services designated as the Owner’s responsibility in Section 4.1.1. § 5.9 If the Owner identified a Sustainable Objective in Article 1, the Owner shall fulfill its responsibilities as required in AIA Document E235™–2019, Sustainable Projects Exhibit, Construction Manager as Adviser Edition, attached to this Agreement. § 5.10 The Owner shall coordinate the services of its own consultants with those services provided by the Construction Manager. Upon the Construction Manager’s request, the Owner shall furnish copies of the scope of services in the contracts between the Owner and the Owner’s consultants. The Owner shall furnish the services of consultants other than those designated as the responsibility of the Construction Manager in this Agreement, or authorize the Construction Manager to furnish them as an Additional Service, when the Construction Manager requests such services and demonstrates that they are reasonably required by the scope of the Project. The Owner shall require that DocuSign Envelope ID: 0D3E110D-2391-4C89-863D-B3011E2F908B Init. / AIA Document C132 – 2019. Copyright © 1973, 1980, 1992, 2009, and 2019. All rights reserved. “The American Institute of Architects,” “American Institute of Architects,” “AIA,” the AIA Logo, and “AIA Contract Documents” are trademarks of The American Institute of Architects. This document was produced at 12:12:01 ET on 08/03/2023 under Order No.3104237575 which expires on 12/12/2023, is not for resale, is licensed for one-time use only, and may only be used in accordance with the AIA Contract Documents® Terms of Service. To report copyright violations, e-mail docinfo@aiacontracts.com. User Notes: (1198159441) 17 its consultants and contractors maintain insurance, including professional liability insurance, as appropriate to the services or work provided. § 5.11 The Owner shall furnish tests, inspections and reports required by law or the Contract Documents, such as structural, mechanical, and chemical tests, tests for air and water pollution, and tests for hazardous materials. § 5.12 The Owner shall furnish all legal, insurance and accounting services, including auditing services, that may be reasonably necessary at any time for the Project to meet the Owner’s needs and interests. § 5.13 The Owner shall provide prompt written notice to the Construction Manager and Architect if the Owner becomes aware of any fault or defect in the Project, including errors, omissions or inconsistencies in the Architect’s Instruments of Service or any fault or defect in the Construction Manager’s services. § 5.14 The Owner reserves the right to perform construction and operations related to the Project with the Owner’s own forces, and to award contracts in connection with the Project which are not part of the Construction Manager’s responsibilities under this Agreement. The Construction Manager shall notify the Owner if any such independent action will interfere with the Construction Manager’s ability to perform the Construction Manager’s responsibilities under this Agreement. When performing construction or operations related to the Project, the Owner agrees to be subject to the same obligations and to have the same rights as the Contractors. § 5.15 The Owner shall communicate with the Contractors and the Construction Manager’s consultants through the Construction Manager about matters arising out of or relating to the Contract Documents. The Owner and Construction Manager shall include the Architect in all communications that relate to or affect the Architect’s services or professional responsibilities. The Owner shall promptly notify the Architect of the substance of any direct communications between the Owner and the Construction Manager otherwise relating to the Project. Communications by and with the Architect’s consultants shall be through the Architect. § 5.16 Before executing the Contracts for Construction, the Owner shall coordinate the Construction Manager’s duties and responsibilities set forth in the Contracts for Construction with the Construction Manager’s services set forth in this Agreement. The Owner shall provide the Construction Manager a copy of the executed agreements between the Owner and Contractors, including the General Conditions of the Contracts for Construction. § 5.17 The Owner shall provide the Construction Manager access to the Project site prior to commencement of the Work and shall obligate the Contractors to provide the Construction Manager access to the Work wherever it is in preparation or progress. § 5.18 Within 15 days after receipt of a written request from the Construction Manager, the Owner shall furnish the requested information as necessary and relevant for the Construction Manager to evaluate, give notice of, or enforce lien rights. § 5.19 The services, information and reports provided by the Owner pursuant to this Article 5 shall be provided at the Owner’s expense, and the Construction Manager shall be entitled to rely upon the accuracy and completeness thereof. ARTICLE 6 COST OF THE WORK § 6.1 For purposes of this Agreement, the Cost of the Work shall be the total cost to the Owner to construct all elements of the Project designed or specified by the Architect and shall include the Contractors’ general conditions costs, overhead and profit. The Cost of the Work also includes the reasonable value of labor, materials, and equipment, donated to, or otherwise furnished by, the Owner. The Cost of the Work includes the compensation of the Construction Manager and Construction Manager’s Consultants during the Construction Phase only, including compensation for reimbursable expenses at the job site, if any. The Cost of the Work does not include the compensation of the Architect; the costs of the land, rights-of-way, financing, or contingencies for changes in the Work; or other costs that are the responsibility of the Owner. § 6.2 The Owner’s budget for the Cost of the Work is provided in Initial Information, and shall be adjusted throughout the Project as required under Sections 5.2 and 6.4. Evaluations of the Owner’s budget for the Cost of the Work, and the estimates of the Cost of the Work prepared by the Construction Manager, represent the Construction Manager’s judgment as a person or entity familiar with the construction industry. It is recognized, however, that neither the DocuSign Envelope ID: 0D3E110D-2391-4C89-863D-B3011E2F908B Init. / AIA Document C132 – 2019. Copyright © 1973, 1980, 1992, 2009, and 2019. All rights reserved. “The American Institute of Architects,” “American Institute of Architects,” “AIA,” the AIA Logo, and “AIA Contract Documents” are trademarks of The American Institute of Architects. This document was produced at 12:12:01 ET on 08/03/2023 under Order No.3104237575 which expires on 12/12/2023, is not for resale, is licensed for one-time use only, and may only be used in accordance with the AIA Contract Documents® Terms of Service. To report copyright violations, e-mail docinfo@aiacontracts.com. User Notes: (1198159441) 18 Construction Manager nor the Owner has control over the cost of labor, materials; or equipment; the Contractors’ methods of determining bid prices; or competitive bidding, market, or negotiating conditions. Accordingly, the Construction Manager cannot and does not warrant or represent that bids or negotiated prices will not vary from the Owner’s budget for the Cost of the Work, or from any estimate of the Cost of the Work, or evaluation, prepared or agreed to by the Construction Manager. § 6.3 If the Architect is providing cost estimating services as a Supplemental Service, and a discrepancy exists between the Construction Manager’s cost estimates and the Architect’s cost estimates, the Construction Manager and the Architect shall work together to reconcile the cost estimates. § 6.4 If the Construction Manager’s estimate of the Cost of the Work exceeds the Owner’s budget for the Cost of the Work, the Construction Manager, in consultation with the Architect, shall make appropriate recommendations to the Owner to adjust the Project’s size, quality, or budget for the Cost of the Work, and the Owner shall cooperate with the Construction Manager and Architect in making such adjustments. § 6.5 If the Construction Manager’s estimate of the Cost of the Work exceeds the Owner’s budget for the Cost of the Work, the Owner shall .1 give written approval of an increase in the budget for the Cost of the Work; .2 terminate in accordance with Section 9.5; .3 in consultation with the Construction Manager and Architect, revise the Project program, scope, or quality as required to reduce the Cost of the Work; or .4 implement any other mutually acceptable alternative. § 6.6 If the Owner chooses to revise the Project program, scope, or quality to reduce the Cost of the Work pursuant to Section 6.5.3, or if the bids or proposals received from the prospective Contractors, in the aggregate, exceed the Owner’s budget for the Cost of the Work, and the Owner chooses to revise the Project program, scope, or quality to reduce the Cost of the Work , the Construction Manager shall cooperate with the Owner and Architect to develop the necessary revisions, update the cost estimate, and obtain additional bids. The Construction Manager will perform the services described in Sections 6.4 and 6.6 without additional compensation. ARTICLE 7 COPYRIGHTS AND LICENSES The Construction Manager and the Construction Manager’s consultants, if any, shall not own or claim a copyright in the Instruments of Service. The Construction Manager, the Construction Manager’s consultants, if any, and the Owner warrant that in transmitting Instruments of Service, or any other information, the transmitting party is the copyright owner of such information or has permission from the copyright owner to transmit such information for its use on the Project. ARTICLE 8 CLAIMS AND DISPUTES § 8.1 General § 8.1.1 The Owner and Construction Manager shall commence all claims and causes of action against the other and arising out of or related to this Agreement, whether in contract, tort, or otherwise, in accordance with the requirements of the binding dispute resolution method selected in this Agreement and within the period specified by applicable law, but in any case not more than 10 years after the date of Substantial Completion of the Work. The Owner and Construction Manager waive all claims and causes of action not commenced in accordance with this Section 8.1.1. § 8.1.2 To the extent damages are covered by property insurance, the Owner and Construction Manager waive all rights against each other and against the contractors, consultants, agents, and employees of the other for damages, except such rights as they may have to the proceeds of such insurance as set forth in AIA Document A232–2019, General Conditions of the Contract for Construction. The Owner or the Construction Manager, as appropriate, shall require of the contractors, consultants, agents, and employees of any of them, similar waivers in favor of the other parties enumerated herein. § 8.1.3 The Construction Manager shall indemnify and hold the Owner and the Owner’s officers and employees harmless from and against damages, losses and judgments arising from claims by third parties, including reasonable attorneys’ fees and expenses recoverable under applicable law, but only to the extent they are caused by the negligent acts or omissions of the Construction Manager, its employees and its consultants in the performance of professional services under this Agreement. The Construction Manager’s obligation to indemnify and hold the Owner and the DocuSign Envelope ID: 0D3E110D-2391-4C89-863D-B3011E2F908B Init. / AIA Document C132 – 2019. Copyright © 1973, 1980, 1992, 2009, and 2019. All rights reserved. “The American Institute of Architects,” “American Institute of Architects,” “AIA,” the AIA Logo, and “AIA Contract Documents” are trademarks of The American Institute of Architects. This document was produced at 12:12:01 ET on 08/03/2023 under Order No.3104237575 which expires on 12/12/2023, is not for resale, is licensed for one-time use only, and may only be used in accordance with the AIA Contract Documents® Terms of Service. To report copyright violations, e-mail docinfo@aiacontracts.com. User Notes: (1198159441) 19 Owner’s officers and employees harmless does not include a duty to defend. The Construction Manager’s duty to indemnify the Owner under this Section 8.1.3 shall be limited to the available proceeds of the insurance coverage required by this Agreement. § 8.1.4 The Construction Manager and Owner waive consequential damages for claims, disputes, or other matters in question, arising out of or relating to this Agreement. This mutual waiver is applicable, without limitation, to all consequential damages due to either party’s termination of this Agreement, except as specifically provided in Section 9.7. § 8.2 Mediation § 8.2.1 Any claim, dispute or other matter in question arising out of or related to this Agreement shall be subject to mediation as a condition precedent to binding dispute resolution. If such matter relates to or is the subject of a lien arising out of the Construction Manager’s services, the Construction Manager may proceed in accordance with applicable law to comply with the lien notice or filing deadlines prior to resolution of the matter by mediation or by binding dispute resolution. § 8.2.2 The Owner and Construction Manager shall endeavor to resolve claims, disputes and other matters in question between them by mediation, which, unless the parties mutually agree otherwise, shall be administered by the American Arbitration Association in accordance with its Construction Industry Mediation Procedures in effect on the date of this Agreement. A request for mediation shall be made in writing, delivered to the other party to this Agreement, and filed with the person or entity administering the mediation. The request may be made concurrently with the filing of a complaint or other appropriate demand for binding dispute resolution but, in such event, mediation shall proceed in advance of binding dispute resolution proceedings, which shall be stayed pending mediation for a period of 60 days from the date of filing, unless stayed for a longer period by agreement of the parties or court order. If an arbitration proceeding is stayed pursuant to this section, the parties may nonetheless proceed to the selection of the arbitrator(s) and agree upon a schedule for later proceedings. § 8.2.3 The parties shall share the mediator’s fee and any filing fees equally. The mediation shall be held in the place where the Project is located, unless another location is mutually agreed upon. Agreements reached in mediation shall be enforceable as settlement agreements in any court having jurisdiction thereof. § 8.2.4 If the parties do not resolve a dispute through mediation pursuant to this Section 8.2, the method of binding dispute resolution shall be the following: (Check the appropriate box.) [ ]Arbitration pursuant to Section 8.3 of this Agreement [ X ]Litigation in a court of competent jurisdiction [ ]Other: (Specify) If the Owner and Construction Manager do not select a method of binding dispute resolution, or do not subsequently agree in writing to a binding dispute resolution method other than litigation, the dispute will be resolved in a court of competent jurisdiction. § 8.3 ArbitrationThe provisions of this Article 8 shall survive the termination of this Agreement. § 8.3.1 If the parties have selected arbitration as the method for binding dispute resolution in this Agreement, any claim, dispute or other matter in question arising out of or related to this Agreement subject to, but not resolved by, mediation shall be subject to arbitration, which, unless the parties mutually agree otherwise, shall be administered by the American Arbitration Association in accordance with its Construction Industry Arbitration Rules in effect on the date of this Agreement. A demand for arbitration shall be made in writing, delivered to the other party to this Agreement, and filed with the person or entity administering the arbitration. DocuSign Envelope ID: 0D3E110D-2391-4C89-863D-B3011E2F908B Init. / AIA Document C132 – 2019. Copyright © 1973, 1980, 1992, 2009, and 2019. All rights reserved. “The American Institute of Architects,” “American Institute of Architects,” “AIA,” the AIA Logo, and “AIA Contract Documents” are trademarks of The American Institute of Architects. This document was produced at 12:12:01 ET on 08/03/2023 under Order No.3104237575 which expires on 12/12/2023, is not for resale, is licensed for one-time use only, and may only be used in accordance with the AIA Contract Documents® Terms of Service. To report copyright violations, e-mail docinfo@aiacontracts.com. User Notes: (1198159441) 20 § 8.3.1.1 A demand for arbitration shall be made no earlier than concurrently with the filing of a request for mediation, but in no event shall it be made after the date when the institution of legal or equitable proceedings based on the claim, dispute or other matter in question would be barred by the applicable statute of limitations. For statute of limitations purposes, receipt of a written demand for arbitration by the person or entity administering the arbitration shall constitute the institution of legal or equitable proceedings based on the claim, dispute or other matter in question. § 8.3.2 The foregoing agreement to arbitrate, and other agreements to arbitrate with an additional person or entity duly consented to by parties to this Agreement, shall be specifically enforceable in accordance with applicable law in any court having jurisdiction thereof. § 8.3.3 The award rendered by the arbitrator(s) shall be final, and judgment may be entered upon it in accordance with applicable law in any court having jurisdiction thereof. § 8.3.4 Consolidation or Joinder § 8.3.4.1 Either party, at its sole discretion, may consolidate an arbitration conducted under this Agreement with any other arbitration to which it is a party provided that (1) the arbitration agreement governing the other arbitration permits consolidation; (2) the arbitrations to be consolidated substantially involve common questions of law or fact; and (3) the arbitrations employ materially similar procedural rules and methods for selecting arbitrator(s). § 8.3.4.2 Either party, at its sole discretion, may include by joinder persons or entities substantially involved in a common question of law or fact whose presence is required if complete relief is to be accorded in arbitration, provided that the party sought to be joined consents in writing to such joinder. Consent to arbitration involving an additional person or entity shall not constitute consent to arbitration of any claim, dispute or other matter in question not described in the written consent. § 8.3.4.3 The Owner and Construction Manager grant to any person or entity made a party to an arbitration conducted under this Section 8.3, whether by joinder or consolidation, the same rights of joinder and consolidation as the Owner and Construction Manager under this Agreement. § 8.4 The provisions of this Article 8 shall survive the termination of this Agreement. ARTICLE 9 TERMINATION OR SUSPENSION § 9.1 If the Owner fails to make payments to the Construction Manager in accordance with this Agreement, such failure shall be considered substantial nonperformance and cause for termination or, at the Construction Manager’s option, cause for suspension of performance of services under this Agreement. If the Construction Manager elects to suspend services, the Construction Manager shall give seven days’ written notice to the Owner before suspending services. In the event of a suspension of services, the Construction Manager shall have no liability to the Owner for delay or damage caused the Owner because of such suspension of services. Before resuming services, the Owner shall pay the Construction Manager all sums due prior to suspension and any expenses incurred in the interruption and resumption of the Construction Manager’s services. The Construction Manager’s fees for the remaining services and the time schedules shall be equitably adjusted. § 9.2 If the Owner suspends the Project, the Construction Manager shall be compensated for services performed prior to notice of such suspension. When the Project is resumed, the Construction Manager shall be compensated for expenses incurred in the interruption and resumption of the Construction Manager’s services. The Construction Manager’s fees for the remaining services and the time schedules shall be equitably adjusted. § 9.3 If the Owner suspends the Project for more than 90 cumulative days for reasons other than the fault of the Construction Manager, the Construction Manager may terminate this Agreement by giving not less than seven days’ written notice. § 9.4 Either party may terminate this Agreement upon not less than seven days’ written notice should the other party fail substantially to perform in accordance with the terms of this Agreement through no fault of the party initiating the termination. § 9.5 The Owner may terminate this Agreement upon not less than seven days’ written notice to the Construction Manager for the Owner’s convenience and without cause. DocuSign Envelope ID: 0D3E110D-2391-4C89-863D-B3011E2F908B Init. / AIA Document C132 – 2019. Copyright © 1973, 1980, 1992, 2009, and 2019. All rights reserved. “The American Institute of Architects,” “American Institute of Architects,” “AIA,” the AIA Logo, and “AIA Contract Documents” are trademarks of The American Institute of Architects. This document was produced at 12:12:01 ET on 08/03/2023 under Order No.3104237575 which expires on 12/12/2023, is not for resale, is licensed for one-time use only, and may only be used in accordance with the AIA Contract Documents® Terms of Service. To report copyright violations, e-mail docinfo@aiacontracts.com. User Notes: (1198159441) 21 § 9.6 If the Owner terminates this Agreement for its convenience pursuant to Section 9.5, or the Construction Manager terminates this Agreement pursuant to Section 9.3, the Owner shall compensate the Construction Manager for services performed prior to termination, and Reimbursable Expenses incurred, and costs attributable to termination, including the costs attributable to the Construction Manager’s termination of consultant agreements. § 9.7 In addition to any amounts paid under Section 9.6, if the Owner terminates this Agreement for its convenience pursuant to Section 9.5, or the Construction Manager terminates this Agreement pursuant to Section 9.3, the Owner shall pay to the Construction Manager the following termination fee: (Set forth below the amount of any termination fee, or the method for determining any termination fee.) Payment for services performed and costs incurred by reason of such termination, along with reasonable profit on services not completed during the Construction Phase. § 9.8 Except as otherwise expressly provided herein, this Agreement shall terminate one year from the date of Substantial Completion. ARTICLE 10 MISCELLANEOUS PROVISIONS § 10.1 This Agreement shall be governed by the law of the place where the Project is located, excluding that jurisdiction’s choice of law rules. If the parties have selected arbitration as the method of binding dispute resolution, the Federal Arbitration Act shall govern Section 8.3. § 10.2 Terms in this Agreement shall have the same meaning as those in AIA Document A232–2019, General Conditions of the Contract for Construction, except for purposes of this Agreement, the term "Work" shall include the work of all Contractors under the administration of the Construction Manager and the Architect. § 10.3 The Owner and Construction Manager, respectively, bind themselves, their agents, successors, assigns, and legal representatives to this Agreement. Neither the Owner nor the Construction Manager shall assign this Agreement without the written consent of the other, except that the Owner may assign this Agreement to a lender providing financing for the Project if the lender agrees to assume the Owner’s rights and obligations under this Agreement, including any payments due to the Construction Manager by the Owner prior to the assignment. § 10.4 If the Owner requests the Construction Manager to execute certificates, the proposed language of such certificates shall be submitted to the Construction Manager for review at least 14 days prior to the requested dates of execution. If the Owner requests the Construction Manager to execute consents reasonably required to facilitate assignment to a lender, the Construction Manager shall execute all such consents that are consistent with this Agreement, provided the proposed consent is submitted to the Construction Manager for review at least 14 days prior to execution. The Construction Manager shall not be required to execute certificates or consents that would require knowledge, services, or responsibilities beyond the scope of this Agreement. § 10.5 Nothing contained in this Agreement shall create a contractual relationship with, or a cause of action in favor of, a third party against either the Owner or Construction Manager. § 10.6 Unless otherwise required in this Agreement, the Construction Manager shall have no responsibility for the discovery, presence, handling, removal or disposal of, or exposure of persons to, hazardous materials or toxic substances in any form at the Project site. § 10.7 The Construction Manager shall have the right to include photographic or artistic representations of the design of the Project among the Construction Manager’s promotional and professional materials. The Construction Manager shall provide professional credit for the Architect and the Contractors in the Construction Manager’s promotional materials for the Project. The Construction Manager shall be given reasonable access to the completed Project to make such representations. However, the Construction Manager’s materials shall not include the Owner’s confidential or proprietary information if the Owner has previously advised the Construction Manager in writing of the specific information considered by the Owner to be confidential or proprietary. The Owner shall provide professional credit for the Construction Manager in the Owner’s promotional materials for the Project. This Section 10.7 shall survive the termination of this Agreement unless the Owner terminates this Agreement for cause pursuant to Section 9.4. DocuSign Envelope ID: 0D3E110D-2391-4C89-863D-B3011E2F908B Init. / AIA Document C132 – 2019. Copyright © 1973, 1980, 1992, 2009, and 2019. All rights reserved. “The American Institute of Architects,” “American Institute of Architects,” “AIA,” the AIA Logo, and “AIA Contract Documents” are trademarks of The American Institute of Architects. This document was produced at 12:12:01 ET on 08/03/2023 under Order No.3104237575 which expires on 12/12/2023, is not for resale, is licensed for one-time use only, and may only be used in accordance with the AIA Contract Documents® Terms of Service. To report copyright violations, e-mail docinfo@aiacontracts.com. User Notes: (1198159441) 22 § 10.8 If the Construction Manager or Owner receives information specifically designated as "confidential" or "business proprietary," the receiving party shall keep such information strictly confidential and shall not disclose it to any other person except as set forth in Section 10.8.1. 10.8.1 and 10.8.2. This Section 10.8 shall survive the termination of this Agreement. § 10.8.1 The receiving party may disclose "confidential" or "business proprietary" information after 7 days’ notice to the other party, when required by law, arbitrator’s order, or court order, including a subpoena or other form of compulsory legal process issued by a court or governmental entity, or to the extent such information is reasonably necessary for the receiving party to defend itself in any dispute. The receiving party may also disclose such information to its employees, consultants, or contractors in order to perform services or work solely and exclusively for the Project, provided those employees, consultants and contractors are subject to the restrictions on the disclosure and use of such information as set forth in this Section 10.8. § 10.8.2 The Parties acknowledge that this Contract is subject to the applicable requirements of Minnesota’s Government Data Practices Act (MGDPA), Minnesota Statutes, Section 13.01 et seq. The Construction Manager agrees to cooperate with the Owner with respect to the Owner’s obligations to comply with the requirements of the MGDPA. Pursuant to Minnesota Statutes, Section 13.05, subd. 11, all of the data created, collected, received, stored, used, maintained, or disseminated by Construction Manager in performing this contract is subject to the applicable requirements of the MGDPA. The terms of this section shall survive the cancellation or termination of this Agreement. § 10.9 The invalidity of any provision of the Agreement shall not invalidate the Agreement or its remaining provisions. If it is determined that any provision of the Agreement violates any law, or is otherwise invalid or unenforceable, then that provision shall be revised to the extent necessary to make that provision legal and enforceable. In such case the Agreement shall be construed, to the fullest extent permitted by law, to give effect to the parties’ intentions and purposes in executing the Agreement. § 10.10 The Construction Manager shall comply with Minnesota Statute § 471.425, Subdivision 4a to the extent it is applicable to this Agreement. ARTICLE 11 COMPENSATION § 11.1 For the Construction Manager’s Basic Services described under Article 3, the Owner shall compensate the Construction Manager as follows: § 11.1.1 For Preconstruction Phase Services in Section 3.2: (Insert amount of, or basis for, compensation, including stipulated sums, multiples or percentages.) Lump Sum of $25,000.00 for 10 months of Preconstruction Phase Services from the date of this Agreement. Should the Preconstruction Phase exceed the above period, the Construction Manager’s time shall be billed at the hourly rates set forth in Section 11.5. § 11.1.2 For Construction Phase Services in Section 3.3: (Insert amount of, or basis for, compensation, including stipulated sums, multiples or percentages.) The Construction Manager shall be paid (i) a fee of 1.60% of the Cost of the Work defined in Article 6, (ii) a stipulated sum of $1,034,600 for administering and managing the project at the hourly rates set forth in Section 11.5.1, (iii) the costs of Construction Manager’s field labor for general conditions work at the hourly rates set forth in section 11.5.2, and (iv) any Reimbursable Expenses. For the Construction Manager’s costs for administrating and managing the Project referenced in Section 11.1.2(ii), the stipulated sum assumes a 20-month schedule for the Construction Phase not including the pause. Should the Construction Phase extend beyond 20 months, the Construction Manager is entitled to charge additional amounts at DocuSign Envelope ID: 0D3E110D-2391-4C89-863D-B3011E2F908B Init. / AIA Document C132 – 2019. Copyright © 1973, 1980, 1992, 2009, and 2019. All rights reserved. “The American Institute of Architects,” “American Institute of Architects,” “AIA,” the AIA Logo, and “AIA Contract Documents” are trademarks of The American Institute of Architects. This document was produced at 12:12:01 ET on 08/03/2023 under Order No.3104237575 which expires on 12/12/2023, is not for resale, is licensed for one-time use only, and may only be used in accordance with the AIA Contract Documents® Terms of Service. To report copyright violations, e-mail docinfo@aiacontracts.com. User Notes: (1198159441) 23 the hourly rates set forth above not to exceed the following: (i) $11,950 per each additional week, or (ii) $51,730 per each additional month. § 11.2 For the Construction Manager’s Supplemental Services designated in Section 4.1.1, and for any Sustainability Services required pursuant to Section 4.1.3, the Owner shall compensate the Construction Manager as follows: (Insert amount of, or basis for, compensation. If necessary, list specific services to which particular methods of compensation apply.) At the hourly rates set forth in Sections 11.5.1 and 11.5.2, plus Reimbursable Expenses. § 11.3 For Additional Services that may arise during the course of the Project, including those under Section 4.2, the Owner shall compensate the Construction Manager as follows: (Insert amount of, or basis for, compensation.) At the hourly rates set forth in Sections 11.5.1 and 11.5.2, plus Reimbursable Expenses. § 11.4 Compensation for Supplemental and Additional Services of the Construction Manager’s consultants when not included in Sections 11.2 or 11.3, shall be the amount invoiced to the Construction Manager plus percent ( %), or as follows: (Insert amount of, or basis for computing, Construction Manager’s consultants’ compensation for Supplemental or Additional Services.) § 11.5 The hourly billing rates for services of the Construction Manager and the Construction Manager’s consultants are set forth below. The rates shall be adjusted in accordance with the Construction Manager’s and Construction Manager’s consultants’ normal review practices. (If applicable, attach an exhibit of hourly billing rates or insert them below.) [OPTION] § 11.5.1 Hourly Rates for administrative and management personnel: Personnel Category Rate Per Hour Project Director $194/ hour Senior Project Manager $166 / hour Project Manager $145 / hour Project Engineer $108 / hour Assistant Project Manager $120 / hour Estimator $145/ hour General Superintendent $151 / hour Project Superintendent $143 / hour Assistant Superintendent $125 / hour Clerical $70 / hour Accounting $70 / hour Safety Manager $135 / hour Quality Manager $143 / hour VDC/BIM $130 / hour The rates set forth above shall be in effect through December 31, 2023. Thereafter the rates shall be increased by Three percent (3%) per year as of January 1 of each subsequent year. § 11.5.2 Regular Hourly Rates for field labor personnel for any miscellaneous general requirements or general conditions-type work: Employee or Category Rate ($0.00) DocuSign Envelope ID: 0D3E110D-2391-4C89-863D-B3011E2F908B Init. / AIA Document C132 – 2019. Copyright © 1973, 1980, 1992, 2009, and 2019. All rights reserved. “The American Institute of Architects,” “American Institute of Architects,” “AIA,” the AIA Logo, and “AIA Contract Documents” are trademarks of The American Institute of Architects. This document was produced at 12:12:01 ET on 08/03/2023 under Order No.3104237575 which expires on 12/12/2023, is not for resale, is licensed for one-time use only, and may only be used in accordance with the AIA Contract Documents® Terms of Service. To report copyright violations, e-mail docinfo@aiacontracts.com. User Notes: (1198159441) 24 Personnel Category Rate Per Hour Carpenter - Journeyman $104.90 / hour Carpenter - Foreman $110.01 / hour Carpenter – General Foreman $114.39 / hour Laborer - Journeyman $95.63 / hour Laborer - Foreman $100.01 / hour Operator – G1 $107.32 / hour Operator – G2 $106.81 / hour Operator – G3 $104.67/ hour Operator – G4 $104.16 / hour Operator – G5 $101.25 / hour Operator – G6 $98.96 / hour Operator – G7 $97.25 / hour Operator – G8 $94.20/ hour The rates set forth above shall be increased in accordance with the terms of any applicable collective bargaining agreement. The rates for any miscellaneous tool or equipment rentals shall be at the rates set forth in Exhibit A. § 11.6 Compensation for Reimbursable Expenses § 11.6.1 Reimbursable Expenses are in addition to compensation for Basic, Supplemental, and Additional Services and include expenses incurred by the Construction Manager and the Construction Manager’s consultants directly related to the Project, as follows: .1 Transportation and authorized out-of-town travel and subsistence; .2 Long distance services, dedicated data and communication services, teleconferences, Project web sites, and extranets; .3 Permitting and other fees required by authorities having jurisdiction over the Project; .4 Printing, reproductions, plots, and standard form documents; .5 Postage, handling, and delivery; .6 Expense of overtime work requiring higher than regular rates, if authorized in advance by the Owner; .7 Professional photography, and presentation materials requested by the Owner; .8 If required by the Owner, and with the Owner’s prior written approval, the Construction Manager’s consultants’ expenses of professional liability insurance dedicated exclusively to this Project, or the expense of additional insurance coverage or limits in excess of that normally maintained by the Construction Manager’s consultants; .9 All taxes levied on professional services and on reimbursable expenses; .10 Site office expenses; .11 General conditions expenditures; .12 Construction collaboration technology .13 General liability, professional liability, and umbrella liability insurance at a rate of 0.95% of the cost of the Construction Manager’s Preconstruction and Construction Phase services; .11 .14 Coordination of warranty work required to be performed by the Contractors after substantial completion of the Project at a rate of 0.15% of the Cost of the Work defined in Article 6; and .15 Other similar Project-related expenditures. § 11.6.2 For Reimbursable Expenses the compensation shall be the expenses incurred by the Construction Manager and the Construction Manager’s consultants plus 1.60 percent ( 1.60 %) of the expenses incurred. § 11.7 Construction Manager’s Insurance. If the types and limits of coverage required in Section 2.8 are in addition to the types and limits the Construction Manager normally maintains, the Owner shall pay the Construction Manager for the additional costs incurred by the Construction Manager for the additional coverages as set forth below. (Insert the additional coverages the Construction Manager is required to obtain in order to satisfy the requirements set forth in Section 2.8, and for which the Owner shall reimburse the Construction Manager.) DocuSign Envelope ID: 0D3E110D-2391-4C89-863D-B3011E2F908B Init. / AIA Document C132 – 2019. Copyright © 1973, 1980, 1992, 2009, and 2019. All rights reserved. “The American Institute of Architects,” “American Institute of Architects,” “AIA,” the AIA Logo, and “AIA Contract Documents” are trademarks of The American Institute of Architects. This document was produced at 12:12:01 ET on 08/03/2023 under Order No.3104237575 which expires on 12/12/2023, is not for resale, is licensed for one-time use only, and may only be used in accordance with the AIA Contract Documents® Terms of Service. To report copyright violations, e-mail docinfo@aiacontracts.com. User Notes: (1198159441) 25 § 11.8 Payments to the Construction Manager § 11.8.1 Initial Payment § 11.8.1.1 An initial payment of Zero ($ 0.00 ) shall be made upon execution of this Agreement and is the minimum payment under this Agreement. It shall be credited to the Owner’s account in the final invoice. § 11.8.2 Progress Payments § 11.8.2.1 Unless otherwise agreed, payments for services shall be made monthly in proportion to services performed. Payments are due and payable upon presentation of the Construction Manager’s invoice. Amounts unpaid thirty ( 30 ) days after the invoice date shall bear interest at the rate entered below, or in the absence thereof at the legal rate prevailing from time to time at the principal place of business of the Construction Manager. (Insert rate of monthly or annual interest agreed upon.) % The rate of interest required by applicable law, or if no such rate is required by applicable law, invoices due and unpaid under this Agreement shall bear interest from the date payment is due at an annual rate of interest of two percent (2%) over the reference rate of interest from time to time announced by U.S. Bank Minneapolis, NA as its reference rate, with each change in interest rate hereunder to become effective on the date the corresponding change in such reference rate as announced by U.S. Bank Minneapolis, NA becomes effective. § 11.8.2.2 The Owner shall not withhold amounts from the Construction Manager’s compensation to impose a penalty or liquidated damages on the Construction Manager, or to offset sums requested by or paid to Contractors for the cost of changes in the Work, unless the Construction Manager agrees or has been found liable for the amounts in a binding dispute resolution proceeding. § 11.8.2.3 Records of Reimbursable Expenses, expenses pertaining to Supplemental and Additional Services, and services performed on the basis of hourly rates shall be available to the Owner at mutually convenient times. ARTICLE 12 SPECIAL TERMS AND CONDITIONS Special terms and conditions that modify this Agreement are as follows: (Include other terms and conditions applicable to this Agreement.) § 12.1 DOCUSIGN ELECTRONIC SIGNING SYSTEM. The Construction Manager has an agreement with DocuSign, Inc. ("DocuSign") with respect to the DocuSign electronic signing system (the "DocuSign System"). The DocuSign System may be used to facilitate the administration and execution of the Owner’s Construction Contracts with the Multiple Prime Contractors, as well as various other Contract Documents requiring signatures. Should the Owner elect to have the Construction Manager use the DocuSign System with respect to any portion of the Project, the Owner acknowledges and agrees that (i) the Owner conducted its own independent investigation and evaluation as to all legal and other considerations related to its decision to use the DocuSign System on the Project, (ii) the Owner did not rely on any advice, recommendations or representations of the Construction Manager in making the Owner’s independent determination to use the DocuSign System on the Project, (iii) the Construction Manager and DocuSign are not affiliated with each other and the Construction Manager does not warrant or guarantee any portion of the DocuSign System, (iv) the Construction Manager does not warrant or guarantee that the DocuSign system complies with or satisfies any legal requirements applicable to its use on the Project, and (v) to the fullest extent permitted by law, the Owner waives, and shall hold harmless and indemnify the Construction Manager from and against, all claims, causes of action, costs, expenses and damages (including reasonable attorney’s fees) arising out of or resulting from the use of the DocuSign System on the Project. ARTICLE 13 SCOPE OF THE AGREEMENT § 13.1 This Agreement represents the entire and integrated agreement between the Owner and the Construction Manager and supersedes all prior negotiations, representations or agreements, either written or oral. This Agreement may be amended only by written instrument signed by both the Owner and Construction Manager. § 13.2 This Agreement is comprised of the following documents identified below: DocuSign Envelope ID: 0D3E110D-2391-4C89-863D-B3011E2F908B Init. / AIA Document C132 – 2019. Copyright © 1973, 1980, 1992, 2009, and 2019. All rights reserved. “The American Institute of Architects,” “American Institute of Architects,” “AIA,” the AIA Logo, and “AIA Contract Documents” are trademarks of The American Institute of Architects. This document was produced at 12:12:01 ET on 08/03/2023 under Order No.3104237575 which expires on 12/12/2023, is not for resale, is licensed for one-time use only, and may only be used in accordance with the AIA Contract Documents® Terms of Service. To report copyright violations, e-mail docinfo@aiacontracts.com. User Notes: (1198159441) 26 .1 AIA Document C132™–2019, Standard Form Agreement Between Owner and Construction Manager as Adviser .2 AIA Document E203™–2013, Building Information Modeling and Digital Data Exhibit, dated as indicated below: (Insert the date of the E203-2013 incorporated into this Agreement.) .3 Exhibits: (Check the appropriate box for any exhibits incorporated into this Agreement.) [ ]AIA Document E235™–2019, Sustainable Projects Exhibit, Construction Manager as Adviser Edition, dated as indicated below: (Insert the date of the E235-2019 incorporated into this agreement.) [ ]Other Exhibits incorporated into this Agreement: (Clearly identify any other exhibits incorporated into this Agreement, including any exhibits identified in Section 4.1.2.) .4 Other documents: (List other documents, if any, forming part of the Agreement.) Exhibit A – Tool and Equipment Rental Rates This Agreement is entered into as of the day and year first written above. This Agreement may be executed in any number of counterparts, each of which when so executed and delivered shall be deemed an original and all of which counterparts, taken together, shall constitute one and the same instrument. Delivery of an executed counterpart of a signature page of this document by facsimile, pdf or other generally accepted electronic means (e.g., DocuSign) shall be effective as delivery of a manually executed counterpart of this document. City of Chanhassen Kraus-Anderson® Construction Company OWNER (Signature)CONSTRUCTION MANAGER (Signature) (Printed name and title)(Printed name and title) DocuSign Envelope ID: 0D3E110D-2391-4C89-863D-B3011E2F908B City ManagerLaurie Hokkanen Patrick Mulcahey Director of Operations 2023 TOOLS/EQUIPMENT RATES Most Often Rented Tools Rates are based on 8 Hr. day, 40 Hr. week, 176 Hr. Month (22 Days) 11/18/2022 Tool Description Weekly Rate Equipment Description Weekly Rate Air Compressor 185 CFM- Diesel $323.33 Jobsite Office Trailer- 8' x 36'$221.57 Air Compressor Twin Tank- Elec $131.32 Jobsite Office Trailer- 10' x 40'$237.14 ATV- Ranger 2- Passenger $251.68 Jobsite Office Trailer- 12' x 60'$308.00 Ladder- Extension 24'$27.21 Blanket- Insulated $9.84 Ladder- Extension 32'$39.90 Bobcat - Auger Head - Round/Hex Shaft $209.48 Ladder- Step, 6', Fiberglass $13.70 Bobcat Attachments- Forks $113.85 Laser- Laser Level- Rotating $55.72 Bobcat Attachments- Grappler Bucket $204.92 Lift- Scissor Lift 19' Reach $283.25 Bobcat Attachments- Hydro Hammer $463.99 Bobcat Attachments- Sweeper w/Attachments $236.09 Cement Mixer-5 cubic ft.-Wheel Barrow Type $48.44 Bobcat- Skid Steer Bobcat (track machine) S590 $787.95 Nailer- Air/Pneumatic- Framing $54.13 Bobcat- Skid Steer Bobcat (tire machine) T590 $543.60 Nailer- Coil Roofing $56.59 Nailer- Powder Actuated $72.96 Carpet Tools- Carpet Puller $176.80 Panther- Floor Stripper Model 7700 $1,783.03 Cart-Trash Cart- 1 Yard $45.10 Planer- Door $45.98 Compactor- Jumping Jack $216.75 Pressure Washer - Gas $167.12 Compactor- Plate Tamper $159.86 Pump Water- 2" Trash $101.80 Containment Unit $53.58 Router $27.86 Cut-Out Tool/Roto-Zip $22.10 Sander - Belt, 3" x 21"$40.59 Drill- SDS Roto Hammer Max $139.71 Saw- Circular 7-1/4"$27.86 Drill- Hammer SDS Roto Hammer 3/8" Corded $55.72 Saw- Compound Miter Sliding 12"$79.59 Drill- Hammer SDS Roto Hammer 3/8" Cordless $61.04 Saw- Partner- Electric $114.76 Drill- 18 Volt $32.63 Saw- Partner- Gas $114.76 Drill- Right Angle 3/8"$22.10 Saw- Port-a-Band $69.86 Saw- Sawzall Cut Saw $38.90 Fan - 36" Barrel $41.56 Saw- Table- 10"$148.56 Fan- Pedestal Fan $59.61 Saw- Walk Behind Concrete Saw $172.13 Forklift- Rough Terrain 5,000#- $809.44 Survey- Eye Level $100.19 Forklift- Pneumatic $331.53 Sweeper- Walk Behind- Battery Powered $271.41 Forklift- Rough Terrain 10,000#- $1,252.76 Wheelbarrow $15.48 Gang Box- Chest Type $22.85 Hammer- Jack Hammer- Electric 60#$72.51 Generator 3800 Watts $87.44 HEPA price does not include filters Generator- Elec Generator 6500 watt $143.90 HEPA-Air Scrubber-500CFM-Blue-16 x 16 $151.66 Glass Cup $16.08 HEPA Aire Scrubber- 2000CFM $154.83 Grinder- 7" $38.90 Grinder- Floor Ginder $163.96 Grinder- 4 1/2"$22.10 Ground Thaw- 6000 sf 1833..33 Exhibit B DocuSign Envelope ID: 0D3E110D-2391-4C89-863D-B3011E2F908B